TABLE OF CONTENTS

​

​

​

CAUTIONARY STATEMENT REGARDING FORWARD-LOOKING STATEMENTS

This Annual Report on Form 10-K (this “Annual Report”), including Management’s Discussion and Analysis of Financial Condition and Results of Operations in Part II, Item 7, contains forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended (the “Securities Act”), and Section 21E of the Securities Exchange Act of 1934, as amended (the “Exchange Act”). All statements contained in this document other than statements of historical fact, including, without limitation, statements regarding future financial performance, business strategies, market size and opportunity, expansion plans, future results of operations, factors affecting EVgo’s performance, estimated revenues, losses, projected costs, prospects, plans and objectives of management, are forward-looking statements. Such statements can be identified by the fact that they do not relate strictly to historical or current facts. When used in this Annual Report, words such as “may,” “will,” “might,” “should,” “could,” “would,” “can,” “expect,” “plan,” “objective,” “seek,” “grow,” “position,” “possible,” “potential,” “outlook,” “forecast,” “strategy,” “budget,” “target,” “if,” “predict,” “anticipate,” “intend,” “believe,” “estimate,” “continue,” “project” and the negative of such terms or other similar expressions may identify forward-looking statements, but the absence of these words does not mean that a statement is not forward-looking. These forward-looking statements are based on EVgo’s current expectations, estimates, projections and beliefs, as well as a number of assumptions concerning future events, and are not guarantees of performance. These forward-looking statements are subject to a number of risks, uncertainties and assumptions, including the risk factors described in EVgo’s filings with the Securities and Exchange Commission (the “SEC”). Moreover, EVgo operates in a very competitive and rapidly changing environment. New risks emerge from time to time. It is not possible for EVgo to predict all risks, nor can it assess the impact of all factors on its business or the extent to which any factor, or combination of factors, may cause actual results to differ materially from those contained in any forward-looking statements EVgo may make. In light of these risks, uncertainties and assumptions, the future events and trends discussed in this document may not occur and actual results could differ materially and adversely from those anticipated or implied in the forward-looking statements. Accordingly, you should not rely upon forward-looking statements as predictions of future events. Forward-looking statements in this Annual Report may include, without limitation, statements about:

EVgo’s SEC filings are available publicly on the SEC’s website at www.sec.gov. The forward-looking statements contained in this Annual Report are based on EVgo’s current expectations and beliefs concerning future developments and their potential effects on the Company. There can be no assurance that future developments affecting EVgo will be those that the Company has anticipated. These forward-looking statements involve a number of risks, uncertainties (some of which are beyond EVgo’s control) or other assumptions that may cause actual results or performance to be materially different from those expressed or implied by these forward-looking statements. Should one or more of these risks or uncertainties materialize, or should any of EVgo’s assumptions prove incorrect, actual results may vary in material respects from those projected in these forward-looking statements. Forward-looking statements in this Annual Report and in any document incorporated herein by reference should not be relied upon as representing EVgo’s views as of any subsequent date and the Company undertakes no obligation to update or revise any forward-looking statements, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.

​

FREQUENTLY USED TERMS

Unless the context indicates otherwise, the following terms have the following meanings when used in this Annual Report:

“AC” means alternating current.

“A&R Nomination Agreement” means the amended and restated nomination agreement entered into on March 24, 2022, by and between the Company and EVgo Holdings, amending and restating the Nomination Agreement.

“Board of Directors” means the board of directors of EVgo Inc.

“Business Combination Agreement” means that business combination agreement entered into on January 21, 2021 by and among CRIS, Thunder Sub and the EVgo Parties, as may be amended from time to time.

“ChaaS” means charging-as-a-service.

“Class A common stock” means Class A common stock of EVgo Inc., par value $0.0001 per share.

“Class B common stock” means Class B common stock of EVgo Inc., par value $0.0001 per share.

“Code” means the U.S. Internal Revenue Code of 1986, as amended.

“common stock” means Class A common stock and Class B common stock.

“Company” means EVgo Inc. and its subsidiaries.

“Company Group” means EVgo Inc., Thunder Sub or any of their subsidiaries (other than EVgo OpCo and its subsidiaries).

“CRIS” means Climate Change Crisis Real Impact I Acquisition Corporation.

“CRIS Business Combination” means the transactions contemplated by the Business Combination Agreement.

“CRIS Close Date” means the closing of the CRIS Business Combination on July 1, 2021.

“DCFC” means direct current fast charging.

“ESG” means environmental, social and governance matters.

“EV” means electric vehicle.

“EVgo” means, prior to the CRIS Close Date, EVgo Holdings and its subsidiaries and, following the CRIS Close Date, EVgo Inc. and its subsidiaries.

“EVgo Holdco” means EVgo Holdco, LLC, a Delaware limited liability company.

“EVgo Holdings” means EVgo Holdings, LLC, a Delaware limited liability company.

“EVgo OpCo” means EVgo OpCo, LLC, a Delaware limited liability company.

“EVgo OpCo A&R LLC Agreement” means the amended and restated limited liability company agreement of EVgo OpCo entered into on July 1, 2021.

“EVgo OpCo Units” means the equity interests of EVgo OpCo.

“EVgo Parties” means EVgo OpCo, EVgo Holdco and EVgo Holdings.

“EVgo Services” means EVgo Services LLC, a Delaware limited liability company.

“Exchange Act” means the Securities Exchange Act of 1934, as amended.

“GAAP” means accounting principles generally accepted in the United States, consistently applied, as in effect from time to time.

“GWh” means gigawatt-hour, a unit of energy that represents one billion watt-hours and is equal to one million kilowatt-hours.

“Initial Public Offering” means CRIS’s initial public offering of units consummated on October 2, 2020.

“IRS” means the Internal Revenue Service.

“JOBS Act” means the Jumpstart Our Business Startups Act of 2012, as amended.

“kW” means kilowatt.

“kWh” means kilowatt-hour.

“LS Power” means LS Power Equity Partners IV, L.P. and its affiliates, unless the context otherwise requires.

“Nasdaq” means The Nasdaq Global Select Market.

“Nomination Agreement” means the nomination agreement entered into on July 1, 2021, by and between the Company and EVgo Holdings, pursuant to which EVgo Holdings has certain director nomination rights.

“NYSE” means The New York Stock Exchange.

“OEM” means original equipment manufacturer.

“PIPE” means the sale of 40,000,000 shares of Class A common stock to the PIPE Investors, for a purchase price of $10.00 per share and an aggregate purchase price of $400,000,000, in a private placement.

“PIPE Investors” means investors in the PIPE.

“PlugShare” means PlugShare LLC, a California limited liability company.

“Private Placement Warrants” means the 6,600,000 warrants purchased by the Sponsor in a private placement simultaneously with the closing of the Initial Public Offering, each of which is exercisable for one share of Class A common stock at $11.50 per share, at a price of $1.00 per warrant, generating gross proceeds of $6,600,000.

“Public Warrants” means the 11,499,988 redeemable warrants sold as part of the units in the Initial Public Offering.

“SEC” means the U.S. Securities and Exchange Commission.

“Securities Act” means the Securities Act of 1933, as amended.

“Sponsor” means CRIS’s sponsor, Climate Change Crisis Real Impact I Acquisition Holdings, LLC, a Delaware limited liability company.

“Sponsor Agreement” means the letter agreement entered into concurrently with the Business Combination Agreement by and among CRIS, the co-investors, the Sponsor and the other initial stockholders, pursuant to which the Sponsor, other initial stockholders and the co-investors agreed, among other things, to vote all of their shares of common stock held or subsequently acquired by them in favor of the approval of the CRIS Business Combination.

“Tax Receivable Agreement” means the tax receivable agreement, entered into on the CRIS Close Date, by and among CRIS, Thunder Sub, EVgo Holdings and LS Power Equity Advisors, LLC, as agent.

“Thunder Sub” means CRIS Thunder Merger LLC, a Delaware limited liability company and wholly owned subsidiary of EVgo Inc.

​

USE OF TRADEMARKS

​

This Annual Report includes trademarks, trade names, and service marks owned by EVgo. EVgo’s trademarks include Connect the Watts^™, EVgo^®, EVgo Advantage^®, EVgo Basic^™, EVgo eXtend^™, EVgo Inside^™, EVgo Optima^™, EVgo PlusMAX^™, EVgo ReNew^™, EVgo Reservations^™, EVgo Rewards^®, Pay with PlugShare^™, PlugShare^®, and PlugShare^® Premium^™. EVgo’s trademarks are either registered or have been used as common law trademarks by EVgo. This Annual Report may contain additional trademarks, trade names, and service marks of others, which are, to EVgo’s knowledge, the property of their respective owners. Solely for convenience, trademarks, trade names, and service marks referred to in this Annual Report appear without the ®, ™ or SM symbols, but such references are not intended to indicate, in any way, that EVgo will not assert, to the fullest extent under applicable law, its rights or the rights of the applicable licensor to these trademarks, trade names, and service marks. EVgo does not intend its use of other parties’ trademarks, trade names, or service marks to imply, and such use or display should not be construed to imply, a relationship with, or endorsement or sponsorship of EVgo by, such other parties.

​

​

PART I

Item 1. Business.

Unless otherwise indicated or unless the context otherwise requires, all references to “EVgo” and the “Company” refer to EVgo Inc. and its subsidiaries.

Overview

EVgo is a leader in EV charging solutions, building and operating the infrastructure and tools needed to expedite the mass adoption of EVs for individual drivers, rideshare and commercial fleets, and businesses. EVgo is one of the nation’s largest public fast charging networks, featuring over 950 fast charging locations across more than 35 states, including stations built through EVgo eXtend, its white label service offering. EVgo is accelerating transportation electrification through partnerships with automakers, fleet and rideshare operators, retail hosts such as grocery stores, shopping centers, and gas stations, policy leaders, and other organizations. With a rapidly growing network and unique service offerings for drivers and partners, EVgo enables a world-class charging experience where drivers live, work, travel and play.

The foundation of the Company’s business is building, owning and operating EV fast charging sites that deliver charging to EVs driven by individuals, commercial drivers and fleet operators. EVgo is prioritizing the build out of ultra-fast chargers, a key market segment that is expected to grow faster than the overall EV charging market. See “— Suppliers and Service Providers — Electricity.” To take advantage of the expected growth in the number of EVs on the road in the United States, the Company continues to expand its network of charging stations, focusing on development of locations with favorable traffic, utilization and financial return characteristics. The Company’s proprietary technology and analytical tools, along with its extensive commercial partnerships with OEMs, fleets and governments, provide a strong competitive edge as it selects, designs and develops new charging stations. Furthermore, EVgo’s robust underwriting standards require its portfolio to meet or exceed a pre-defined internal rate of return before project approval.

EVgo’s partnerships and collaboration with a wide range of automotive OEMs, rideshare operators and other channel partners are designed to incentivize and accelerate EV adoption across the U.S. Through these partnerships, EVgo’s network powered more than 395 million electric miles during 2023. Total miles delivered is equal to the number of kWh EVgo has dispensed multiplied by the number of miles the average EV receives from a single kWh (“vehicle efficiency”). The weighted average vehicle efficiency from all vehicles compatible with the EVgo network in operation at the end of each year is based on 2023 data from Experian and the U.S. Department of Energy. The weighted average vehicle efficiency is applied to the EVgo kWh dispensed in the associated period.

EVgo also serves the rapidly growing EV fleet segment with the fastest growing segments being rideshare and autonomous rideshare. Reliable and flexible charging is essential to fleet electrification. The Company is able to deploy fleet-charging solutions for light-, medium-, and heavy-duty EV fleets, and EVgo is developing, building, operating and servicing charging assets for fleets at their own depot locations, at off-site charging hubs that EVgo has secured, or via EVgo’s expansive public network. To date, fleet contracts have either been structured as volumetric agreements or included guaranteed payment streams in exchange for guaranteed network access.

To complement its core business model and increase customer reach, EVgo also offers EVgo eXtend, a white label solution, primarily under its charging infrastructure agreement (the “Pilot Infrastructure Agreement”) with Pilot Travel Centers LLC (the “Pilot Company”). EVgo eXtend helps partners invest in and build EV charging stations for use by their customers. Through EVgo eXtend, EVgo leverages its decade-plus track record of operational experience and site design, helping businesses develop charging assets that are serviced through (and often co-branded with) EVgo’s national network. EVgo generates revenue from site development, equipment delivery, engineering and construction activities related to EVgo eXtend stations, as well as ongoing revenue through operations, networking and maintenance of those sites.

In addition to the provision of EV charging infrastructure, EVgo is continuing to develop and deploy innovative software-based, value-added services to drivers and partners. These offerings enhance the customer experience across EVgo’s business segments by layering proprietary technology functionality on top of its charging network, with the intention of creating a competitive advantage and providing accretive revenue streams.

EVgo has a customizable mobile app to make charging simple for EV drivers, delivering a user experience that makes switching to an EV more inviting. Features such as EVgo’s Autocharge+, which enables drivers who register an eligible EV to start a charge simply by plugging in, EVgo Reservations, EVgo Rewards and EVgo Advantage further enhance the driver experience and provide a clear differentiation from other charging providers. Certain other features such as EVgo Inside, which provides a suite of application programming interfaces (“APIs”) that enable a third party to embed the complete EVgo experience into their branded applications, are designed to enhance B2B partner experiences with EVgo. EVgo Inside is used by some of EVgo’s largest customers including GM, Toyota, and Lyft.

EVgo also owns PlugShare, which is a leading global platform for EV drivers to locate and provide information relating to charging stations and provide feedback on their charging experiences, while leveraging tools like PAY WITH PLUGSHARE, which is available across a portion of the EVgo network, and EV Trip Planner. Beyond its services to EV drivers, PlugShare delivers data to automakers and other customers through the PlugShare API and manages the world’s largest EV driver research panel through PlugInsights. PlugShare also delivers advertising impressions globally on behalf of its advertising customers.

Company History

EVgo Services was formed in October 2010 as NRG EV Services, LLC, a Delaware limited liability company and wholly owned subsidiary of NRG Energy, Inc. (“NRG”), an integrated power company based in Houston, Texas. EVgo Services began operations in 2011. On June 17, 2016, NRG sold a majority interest in EVgo Services to Vision Ridge Partners. On January 16, 2020, a subsidiary of LS Power, a private equity investment vehicle focused on power and energy infrastructure, completed its acquisition of EVgo.

The Company was incorporated in Delaware on August 4, 2020 under the name “Climate Change Crisis Real Impact I Acquisition Corporation”. The Company was formed for the purposes of entering into a merger, capital stock exchange, asset acquisition, stock purchase, reorganization or similar business combination with one or more businesses.

On the CRIS Close Date, EVgo Holdco consummated the CRIS Business Combination, with CRIS, Thunder Sub and the EVgo Parties pursuant to the Business Combination Agreement. Following the CRIS Close Date, the combined company is organized in an “Up-C” structure in which the business of EVgo Holdco and its subsidiaries are held by EVgo OpCo and continue to operate through the subsidiaries of EVgo Holdco and in which the Company’s only direct assets consist of equity interests in Thunder Sub, which, in turn, holds only EVgo OpCo Units.

Market Overview

The EV charging market is inextricably linked to the general market for EVs, which continues to experience significant growth. For the year end December 31, 2023, new battery EV sales in the United States were approximately 1.2 million, an increase of 44% compared to 2022, according to Cox Automotive. Market growth is driven by tailwinds such as increased EV model availability and performance, lower upfront prices for EVs, lower total cost of ownership (“TCO”) as compared to internal combustion engine (“ICE”) vehicles, increased range and availability of chargers and federal, state and local incentives and regulations. In response to the growing electrification trend, nearly all major automobile manufacturers have committed to the production of EV models, with over 75 EV models expected to be available in the U.S. in 2024 from over 35 manufacturers. Additionally, major automobile manufacturers have set aggressive targets for EV production and sales. According to forecasts from the United States Department of Transportation and Bloomberg New Energy Finance (“BNEF”), it is expected that approximately nine million EVs will be on roads in the U.S. by 2025, over 37 million EVs by 2030 and over 139 million EVs by 2040, which would represent approximately 59% of all motor vehicles in the U.S.

Automobile and battery manufacturers are offering EVs at a wider range of price points and developing batteries with higher efficiencies and lower costs. According to a 2023 report by Bloomberg, significant EV investment is expected to

be made globally through 2030 by participants in the EV charging industry. Their investments are expected to expand and put EVs and their associated technologies into mass production, which in turn is expected to underpin optimization of the global EV supply chain. Efforts to date by OEMs have already lowered the upfront costs of EVs, with further price reductions expected over the next several model years. As measured in terms of TCO, certain classes of EVs are already at or below parity with their ICE counterparts. As overall EV costs decline, it is expected that greater numbers of EV models will reach TCO parity with their ICE equivalents and that the TCO advantage for other types of EVs will expand.

In addition to price and TCO decreases, widespread adoption of EVs will require consumer confidence in vehicle range, charger availability and increased model choice. In the U.S., 25 EV models have eclipsed 300 miles of range on a full charge, a notable improvement compared to earlier EV models. Researchers and automotive engineers expect that EV ranges will continue to improve as battery technologies advance and costs decline over time. Beyond increases in range, broadly expanded EV offerings in the sport utility vehicle (“SUV”), crossover utility vehicle and pickup truck segments over the next several years are expected to greatly expand the market appeal and reach of EVs and further accelerate adoption of EVs.

These advances are further supported by incentives and rebates offered by federal, state and local governments to encourage the adoption of EVs. In November 2021, Congress passed and the President signed the Infrastructure Investment and Jobs Act (“IIJA”), also known as the Bipartisan Infrastructure Law. Among other provisions, this legislation included up to $7.5 billion in funding for EV charging infrastructure through the Department of Transportation. The U.S. federal government previously offered a tax credit for qualified plug-in EVs with a minimum credit of $2,500 and a maximum credit of $7,500, depending on vehicle weight and battery capacity. In August 2022, the President signed into law the Inflation Reduction Act (“IRA”), which modified and extended the previous EV tax credit and created new tax credits for previously owned EVs and commercial vehicles. The legislation included new domestic content and critical mineral sourcing requirements and eliminated a cap on the availability of tax credits for individuals who purchased vehicles from OEMs that had reached certain production levels. The IRA also expanded, extended, and introduced new eligibility requirements for the tax credit for electric vehicle service equipment (“EVSE”) under Section 30C of the Code. Several states also offer various rebates, grants and tax credits to incentivize both EV purchases and leases, and pursuant to the IIJA, funding became available in 2023 for EVSE nationwide through grant programs administered by state departments of transportation.

Demand for EVs has also been encouraged by regulatory developments and changes in consumer habits. Several states have adopted or proposed mandates for EVs, and California alone has set an aggregate goal of more than seven million EVs on the road by 2030, which, by California Energy Commission estimates, will require one million private and shared public chargers. Additionally, California has enacted its Clean Miles Standard and Incentive Program (the “Clean Miles Standard”) aiming to reduce greenhouse gas emissions from transportation networking companies, such as rideshare vehicles, through electrification and other means. California’s Advanced Clean Truck (“ACT”) rule requires an increasing percentage of medium- and heavy-duty trucks sold in the state to be zero emissions, and several other states have also adopted the ACT rule. These regulations, combined with a shift toward car-sharing and mobility as a service offering, are expected to rapidly accelerate EV adoption by fleets in the coming years.

EV charging demand is driven by the number of EVs operating during a given period, miles traveled by such EVs and vehicle efficiency of such EVs. The market for fulfilling charging demand is bifurcated between high-powered DC fast and ultra-fast charging and lower powered Level 1 (defined below) and Level 2 (defined below) charging. The relative demand for different charging types is a function of the EV mix, owner demographics, locational factors, charger availability, pricing and EV use cases (e.g., private ownership, rideshare, commercially and municipally owned fleets, etc.). Lower-powered Level 1 and Level 2 charging is primarily used by EV owners with access to home or workplace charging and currently accounts for the majority of personal EV charging. Level 2 charging is also used by certain fleets that have the ability to charge overnight, have a low daily mileage requirement and return to a centralized location daily. Current DCFC customers are primarily those drivers who need to charge away from home for convenience or due to long-distance travel, those drivers who do not have access to home or workplace charging or high-mileage fleets that seek to minimize downtime and maximize miles traveled.

Broadening demographics of EV owners, larger battery sizes, larger EVs with higher kWh usage per mile, increased EV penetration in medium- and heavy-duty vehicle applications, increasing adoption of rideshare and last-mile delivery services, and the proliferation of autonomous vehicle fleets are expected to increase demand for DCFC faster than demand

for overall EV charging. According to 2023 forecasts from BNEF, fast charging is expected to constitute approximately 40% of all EV charging demand by 2030.

EV Chargers and Standards

EVgo deploys a DC fast charging station architecture that may include modular power units that are placed under software management and control, allowing power output to be shared dynamically between vehicles that are simultaneously connected to a charger. This dynamic power sharing technology reduces upfront capital and ongoing operating costs, maximizing return on investment, while increasing operational flexibility and lowering operating risk, allowing EVgo to meet increasing charging requirements of the future, including higher charging speeds, higher power provisioning, dynamic energy and demand management, access prioritization, queuing management and scheduling across different EV models, customer types and use cases. This modular software-defined design maximizes charger throughput, asset utilization and ease of future power augmentation while reducing single points of failure risks and improving charger reliability and availability. It also maximizes the number of standardized equipment components, helping to accelerate the learning rate benefits and associated cost reductions of charging hardware over time and improving the ability to offer higher value-added service offerings in the future.

As EVs proliferate in the transportation ecosystem, the industry is shifting toward the standardization of chargers and the introduction of new industry protocols for interoperability.

EV chargers do not come with a “one size fits all” dispenser. EV chargers are typically categorized by their ability to deliver instantaneous amounts of power — as measured in kWs — and their charging standards. Current designations based on power level include:

In addition to supporting different charging capabilities, EVs in the U.S. use different charging standards and connector types. These standards are neither interchangeable nor interoperable (without specialized adaptors), and each utilizes a unique connector. Each EV charging standard generally delivers energy through cables that connect the EV charging station directly to the vehicle using a port located on the exterior of the vehicle. There are currently three standards in use in the U.S. — CCS, CHAdeMO and the North American Charging Standard (“NACS”).

EVgo’s chargers support each of the fast-charging standards described above. EVgo’s first generation DC fast charging stations contain both CCS and CHAdeMO cables with the current generation of DC fast charging stations including only CCS cables. Additionally, certain EVgo charging sites offer integrated Tesla charging, allowing Tesla drivers to charge without needing a separate adaptor. All of EVgo’s CCS stations are also accessible to eligible Teslas through the CCS adaptor, and with EVgo’s Autocharge+, EVgo can deliver the same plug and charge experience to Tesla drivers that they have on the Tesla super charger network. In addition, EVgo has announced that it will be adding NACS connectors to its fast charging network in 2025; however, integrating NACS connectors in future charger installations and on certain existing chargers will require significant investment and management attention. Continuing to develop access to seamless, integrated charging for all EV drivers is a core commitment of EVgo.

Products and Services

Retail Charging

The Company sells electricity directly to drivers who access EVgo’s publicly available networked chargers. Various pricing plans exist for customers, and drivers have the choice to charge through a subscription offering or a variety of pay-as-you-go plans. Drivers locate the chargers through EVgo’s mobile application, their vehicle’s in-dash navigation system, or third-party databases, such as PlugShare, that license charger-location information from EVgo. EVgo’s chargers are generally installed in parking spaces owned or leased by commercial or public-entity Site Hosts that desire to provide charging services at their respective locations. Commercial Site Hosts include retail and grocery stores, offices, medical complexes, airports and convenience stores. EVgo’s offerings are well aligned with the goals of Site Hosts, as many commercial businesses increasingly view charging capabilities as essential to attracting tenants, employees, customers and visitors and achieve sustainability goals. Site Hosts are generally able to obtain these benefits at no cost when partnering with EVgo through the Company’s owner and/or operator model, in which EVgo is responsible for the development, construction and operation of chargers located on Site Hosts’ properties. In many cases, Site Hosts will earn revenue from license payments in the form of parking space rental fees that EVgo pays in exchange for use of the site.

OEM Charging and Related Services

EVgo is a pioneer in OEM charging programs with revenue models to meet a wide variety of OEM objectives related to the availability of charging infrastructure and the provision of charging services for EV drivers. EVgo contracts directly with OEMs to provide charging services to drivers who have purchased or leased such OEMs’ EVs and who access EVgo’s public charger network. Other related services EVgo currently provides to OEMs include co-marketing, data services, and digital application services. EVgo’s OEM relationships are a core customer-acquisition channel.

Commercial Charging

Fleet and Rideshare Public Charging. High volume fleet customers, such as transportation networking companies or delivery services, can access charging infrastructure through EVgo’s vast public network. Pricing for charging services is most often negotiated directly with the fleet owner based on the business needs and usage patterns of the fleet. In these arrangements, EVgo contracts with and bills, either the fleet owner directly or an individual fleet driver utilizing EVgo’s chargers.

Fleet Dedicated Charging. In addition to offering access to its public network, EVgo offers dedicated charging solutions to fleets. Through its fleet product, EVgo develops, builds, and services charging assets for fleets either at their own depot locations or at off-site charging hubs that EVgo has secured without requiring a fleet to directly incur capital expenditures. EVgo offers a variety of pricing models for dedicated charging solutions, including a mix of volumetric commitments and variable and fixed payments for provision of charging services. Together, EVgo’s dedicated charging solutions and public fleet charging services provide fleets with charging infrastructure options that are robust and flexible as the transition to electrified transportation accelerates.

EVgo eXtend

Through EVgo eXtend, EVgo provides hardware, design, and construction services for charging sites, as well as ongoing operations, maintenance and networking and software integration solutions, while customers purchase and retain ownership of the charging assets. Existing customers with EVgo accounts are able to access eXtend chargers through the EVgo app, among other options. For some EVgo eXtend customers, EVgo also provides grant application support and related services.

Ancillary Service Offerings

In addition to charging services, EVgo offers a variety of software-driven digital, development and operations services to customers. These offerings currently include customization of digital applications, charging data integration, loyalty programs, access to chargers behind parking lot or garage pay gates, microtargeted advertising and charging reservations as well as all services provided under PlugShare such as data, research and advertising services and equipment procurement and operational services for customers operating dedicated networks. EVgo continues to evaluate and engage in opportunities to use its foundational expertise in charging infrastructure to provide value-added services to the rapidly growing EV ecosystem.

Market Opportunity & Strategy

The U.S. EV market continues to experience significant growth, and the market share of EVs was approximately 7.6% of all vehicle sales in 2023 according to Kelley Blue Book. As adoption accelerates and the market continues to scale, the availability of appropriate charging infrastructure is critical to enabling consumer and commercial adoptions of EVs. Larger (and thus heavier) EV models, such as SUVs and trucks, being made widely available in the coming years, coupled with an increased number of EV fleets, will require a greater number of easily accessible charging outlets. Further, DC charging is expected to grow faster than the overall charging market as EV range increases, battery density grows and as EV driver demographics and EV use cases expand. Access to convenient and affordable charging is key to accelerating EV adoption, and EVgo’s portfolio of public and dedicated high-powered DCFC positions EVgo to take advantage of broadening electrification trends.

EVgo is differentiated as an operator of charging infrastructure focused on high traffic, high density urban, suburban and exurban areas. EVgo has an extensive track record in optimized site selection, site development, planning, equipment procurement, engineering, construction and operation. In addition, EVgo’s robust underwriting standards underpin disciplined capital allocation. Experience as an asset owner and operator also provides the essential ingredients for being a partner of first resort in provision of white label services, creating increased optionality to provide charging services to emerging segments.

The EVgo team has an extensive skillset and expertise in network planning, site selection, site development, permitting and engineering, equipment specification and procurement, site construction and commissioning, as well as operations, maintenance and networking of a distributed network of DCFCs across the country.

The core elements of this ongoing strategy include:

Competition

The charging infrastructure sector is evolving as the EV market grows and expands to serve new drivers, and it is likely to become increasingly competitive. Key parts of the charging value chain include charging equipment manufacturing and sales, charging network operation and ownership, charging software development, and the provision of e-mobility services. The EV charging companies currently operating in the U.S. — like Blink, ChargePoint, Electrify America, IoTecha, Shell Recharge Solutions (formerly Greenlots and Volta), Tesla, Tritium, and a few electric utilities — are involved with various parts of this value chain. Given the relatively early stage of electrification as a sector, the business models being pursued by each company are still in flux. In general, charging sector incumbents may expand their product offerings and sales strategies and new well-capitalized competitors may enter the market.

As the charging sector continues to evolve, a number of players have emerged or could emerge as competitors of EVgo. As a leading builder, owner and operator of a public fast-charging network, EVgo’s competitors include Blink, Borg Warner (formerly Rhombus), BP, ChargePoint, Electrify America, Flo, IoTecha, Shell Recharge Solutions (formerly Greenlots and Volta), TerraWatt, Tesla, Tritium, and Voltera, as well as the limited number of utilities granted permission by their regulators to own charging assets. Additionally, in 2023, a number of OEMs, including BMW, GM, Honda, Hyundai, Kia, Mercedes-Benz and Stellantis, formed Ionna, a joint venture, for the purpose of building a large EV charging network in North America. As a provider of integrated fleet solutions, EVgo’s competitors include Blink, BP, ChargePoint, Electrify America, Flo, Shell Recharge Solutions (formerly Volta), TerraWatt, Tritium, and Voltera, and utilities could emerge as a competitive force in the future, as well as other pure play charging companies aiming to capitalize on the fleet electrification trend.

The principal competitive factors in the industry include charger count, locations, accessibility and quality of the customer experience; DCFC network availability and reliability, scale and local density; charger connectivity to EVs and ability to charge all standards; speed of charging relative to expected vehicle dwell times at the location; software-enabled services; operator brand, track record and reputation; access to equipment vendors and service providers; access to public policy support and pricing; and access to capital to support network expansion.

Barriers to entry in the EV charging market may erode as a result of government intervention and various support programs, leading to more competitors with a variety of profitability objectives. EVgo has competitive advantages in delivering charging services driven by network scale, network design, experience developing and operating DCFC infrastructure, OEM partnerships, fleet and rideshare partnerships, brand equity, longstanding reputation in the industry, a well-established supply chain, differentiated station design and software enabled service offerings and network effects driven by a large number of repeat customers. Competition arising from use of other types of alternative fuel vehicles such as plug-in hybrid EVs, hydrogen, and high fuel economy gasoline and diesel-powered vehicles could inhibit growth in the EV sector.

Suppliers and Service Providers

Charging Equipment and Related Services

EVgo relies on third-party vendors for design, testing and manufacturing of charging equipment. At this stage of the industry, equipment is unique to each supplier with respect to components and aftermarket maintenance and warranty services. As such, equipment and services are currently singularly sourced from each supplier. For the year ended December 31, 2023, Delta provided 76.9% of EVgo’s total charging equipment. For the year ended December 31, 2022, Delta and Graybar Electric collectively provided 81.9% of EVgo’s total charging equipment.

EVgo has invested in and maintains long-term relationships with suppliers and service providers. EVgo designs stations and specifies EV chargers in-house and outsources production to an assortment of manufacturers. Based on a rigorous certification and qualification testing process, the Company has established commercial relationships with multiple EV charger manufacturers. EVgo typically contracts with and manages specialized electrical and civil contractors to perform station construction and maintenance activities. Additionally, EVgo’s charger management software platform was developed and is operated by Driivz.

Electricity

During 2023, electricity was purchased for charging stations directly from local utilities as a commercial and industrial customer for approximately 75% of EVgo’s charging sites, with these sites representing approximately 90% of EVgo’s total GWh throughput. Each site qualifies for a certain utility tariff based primarily on maximum instantaneous electric usage measured over a historic period. A typical electricity tariff for a site consists of (i) a fixed charge, generally based on the number of meters on site, (ii) an energy charge based on kWh used, which may vary depending on time of use (including seasons and peak hours), (iii) a demand charge, or cost charged per kW during the applicable calculation period, which is often monthly, but which may also vary depending on time of use and (iv) any applicable state and utility taxes. The remainder of EVgo’s charging sites obtain electricity through the Site Host. EVgo generally reimburses the Site Host for the cost of the electricity at a pre-negotiated rate, subject to the terms of each Site Host agreement. The negotiated rate varies based on the Site Host’s electricity tariff, the size of the charging site and other financial incentives provided to the Site Host.

Customers, Partnerships and Strategic Relationships

EVgo has established partnerships and strategic relationships with key OEMs, including GM, Nissan, and Toyota, Site Hosts and fleet operators, as discussed further below. These relationships allow EVgo to access new customers and build brand awareness through co-marketing. EVgo may also benefit from promotional programs sponsored by OEMs. In some cases, OEM partners have agreed to provide one-time or ongoing payments related to the build-out of EVgo’s charger network. In nearly all cases, EVgo retains ownership of the chargers built under these OEM programs.

EVgo has established, invested in and maintained long-term relationships with Site Hosts with national and regional multi-site portfolios of commercial and retail properties. EVgo’s Site Hosts span a wide array of industries and locations, including airports, automobile dealers, healthcare/medical facilities, hotels, mixed-use facilities, municipal locations, parks and recreation areas, parking lots, restaurants, retailers, schools and universities, stadiums, supermarkets, transportation hubs and workplace locations. EVgo executes numerous master agreements with Site Hosts that enable the conversion of prospect sites into develop-able locations by standardizing terms and conditions for site control. EVgo’s ownership model is attractive to Site Host partners as it allows them to offer an EV charging amenity to their customers without needing to incur upfront capital expenditures or ongoing operating costs while generating rent revenue from EVgo. The benefits offered to Site Hosts through EVgo’s business model continue to provide EVgo access to the highest quality property owners, grocery store chains, parking garages, airports and convenience stores.

The Company had two customers that collectively comprised 45.7% of the Company’s total net accounts receivable as of December 31, 2023 and one customer that comprised 20.5% of the Company’s total net accounts receivable as of December 31, 2022. For the year ended December 31, 2023, one customer represented 45.2% of the Company’s total revenue. For the year ended December 31, 2022, two customers collectively represented 42.9% of the Company’s total revenue. As EVgo and the EV industry continue to grow, EVgo expects revenues will be generated from a larger and an

increasingly diverse group of customers and commercial partners. In the ordinary course of business, EVgo engages in active discussions and renegotiations with EVgo’s commercial partners with respect to the solutions it provides and the terms of its agreements, including fees. Most of EVgo’s contracts with EVgo’s commercial partners have multi-year terms and some have rights to terminate prior to the end of the term. The loss of any of EVgo’s largest commercial partners or the renegotiation of any of EVgo’s largest contracts with its commercial partners could adversely affect EVgo’s results of operations.

General Motors Agreement

On July 20, 2020, EVgo entered into a five-year contract with General Motors LLC (“GM”) (as amended from time to time, the “GM Agreement”) to build fast charger stalls that EVgo will own and operate as part of the Company’s public network. The GM Agreement has been amended several times to expand the overall number of charger stalls to be installed from 2,750 to 3,250, adjust charger stall installation targets, extend the completion deadline to March 31, 2026, and provide for a payment of $7,000,000 in December 2022 in exchange for EVgo’s agreement to apply certain branding decals on the fast chargers funded by GM pursuant to the GM Agreement and maintain a specified uptime percentage (described below) over the term of the agreement. Pursuant to the GM Agreement, EVgo is required to meet certain quarterly milestones measured by the number of charger stalls installed, and GM is required to make certain payments based on charger stalls installed.

Under the GM Agreement, EVgo is required to install a total of 3,250 charger stalls by March 31, 2026, 45% of which were installed by December 31, 2023. Meeting the quarterly milestones will require additional funds beyond the amounts committed by GM, and EVgo may face delays in construction, commissioning or aspects of installation of the charger stalls the Company is obligated to develop. EVgo is also required to maintain network availability (i.e., the percentage of time a charger is operational and available on the network) of at least 95% across the GM network. In addition to the capital build program, EVgo is required to provide GM EV customers with reservations and certain EVgo services at a discounted rate and branding on chargers.

The GM Agreement is subject to early termination in certain circumstances, including in the event EVgo fails to meet the quarterly charger stall-installation milestones or maintain the specified level of network availability. If GM opts to terminate the agreement, EVgo may not be entitled to receive continued payments from GM and instead may be required to pay liquidated damages to GM. In the event EVgo fails to meet a charger stall-installation milestone or maintain the required network availability in a calendar quarter, GM has the right to provide EVgo with a notice of such deficiency within 30 days of the end of the quarter. If the same deficiency still exists at the end of the quarter immediately following the quarter for which a deficiency notification was delivered, GM may immediately terminate the agreement and seek pre-agreed liquidated damages of up to $15.0 million.

Nissan Agreement

EVgo executed an agreement with Nissan North America, Inc. (“Nissan”) in June 2019 (the “Nissan Agreement”), that provides for joint marketing activities, charging credit programs for purchasers or lessees of Nissan EVs, and a capital-build program. The Nissan Agreement has been amended several times to, among other things, adjust the allocation of the value of unused charging credits and to provide new offerings for purchasers or lessees of certain Nissan EV models. Under the joint-marketing activities provisions of the Nissan Agreement, EVgo was obligated to spend a specified amount annually on joint-marketing activities that were mutually agreed-upon with Nissan until March 1, 2024. Under the charging credit program provisions in the Nissan Agreement, credits for charging are allocated to purchasers or lessees of Nissan EVs, and such purchasers or lessees are permitted to charge their EV for 12 months at no charge to the participant, up to the amount of the charging credit allocated to such participant or on an unlimited basis, depending on the model of Nissan EV purchased or leased. In the event a participant does not use the entire amount of the allocated charging credit or if the annual charging credit pool is not exhausted within a specific period, a portion of the remaining dollar value of such credit rolls over to subsequent periods, and a portion is retained by the Company. For Nissan EV purchasers or lessees receiving unlimited charging, the Company receives an upfront activation fee for each purchaser or lessee as well as a usage-based fee. The capital-build program provided for in the Nissan Agreement requires the Company to install, operate and maintain public, high-power dual-standard chargers in specified markets pursuant to a schedule that outlines the build timelines for the chargers to be constructed (the “Build Schedule”). If the Company fails to meet its Build Schedule obligations, Nissan may invoke a penalty of up to $70,000 per delayed site beyond a designated cure period, which could result in an

adjustment to the consideration received by the Company under the Nissan Agreement. EVgo and Nissan previously agreed to amend the Nissan Agreement to extend the installation deadlines under the Build Schedule by up to 12 months, and Nissan has waived penalties for installation delays relating to program year one.

EVgo’s ability to meet its Build Schedule obligations may be impacted by delays in permitting, commissioning and utility interconnection, as well as delays related to industry and regulatory adaptation to the requirements of high-powered charger installation, including slower than expected third-party approvals of certain site acquisitions and site plans by utilities and landowners, and supply chain issues.

Pilot Infrastructure Agreement

On July 5, 2022, EVgo entered into the Pilot Infrastructure Agreement and an operations and maintenance agreement (the “Pilot O&M”) with the Pilot Company and GM to build, operate and maintain up to 2,000 stalls served by DC chargers that the Pilot Company will own. The stalls will be located at the Pilot Company sites across the U.S.

Pursuant to the Pilot Infrastructure Agreement, EVgo is required to meet certain construction milestones measured by the number of sites commissioned, and the Pilot Company is required to make certain payments each month based on completion of pre-engineering and development work, the progress of construction at each site and for each charger procured by EVgo. Subject to extensions of time for specified excusable events, if EVgo is unable to meet its commissioning obligations, the Pilot Company will be entitled to liquidated damages calculated per day, subject to a cap of $30,000 at each site. The Pilot Infrastructure Agreement contains various provisions that may permit or cause early termination, including the Pilot Company’s right to terminate after 1,000 stalls have been completed, the inability of EVgo to secure certain chargers and a material increase in the price of chargers due to a change in law. If the Pilot Company elects to terminate the Pilot Infrastructure Agreement after 1,000 stalls have been completed, the Pilot Company must pay EVgo a termination fee per stall for those not built; such fee varies based on the number of stalls already built. If EVgo is wholly or partially unable to perform its obligations under the Pilot Infrastructure Agreement due to certain circumstances outside its control, including delays by permitting authorities and utilities or certain force majeure events, such inability will not be considered a breach or default under the Pilot Infrastructure Agreement.

Under the Pilot O&M, EVgo is required to perform operations, maintenance and networking services on stalls built and commissioned under the Pilot Infrastructure Agreement in exchange for payment of a monthly fee by the Pilot Company to EVgo. EVgo is subject to certain performance criteria under the Pilot O&M.

Intellectual Property

EVgo protects its intellectual property and proprietary rights through patent, trademark, copyright, trade secret and unfair competition laws, and by confidentiality protocols. EVgo undertakes actions as it deems necessary to ensure that its proprietary rights are protected, while at the same time respecting the intellectual property rights of other persons.

As of December 31, 2023, EVgo held 23 patents and had 10 additional patent applications pending in the U.S. and abroad. EVgo continues to regularly assess opportunities for seeking patent protection for those aspects of EVgo’s technology, designs and methodologies that provide a meaningful competitive advantage to the Company.

Governmental Regulation

State, regional and local regulations for installing EV charging stations vary from jurisdiction to jurisdiction and may include permitting requirements, inspection requirements, licensing of contractors and certifications.

The federal National Institute of Standards and Technology’s Handbook 44 (“Handbook 44”) establishes a model weights and measures code, which covers numerous measuring and weighing devices including EV chargers. Handbook 44 is written and amended by the National Conference on Weights and Measures (“NCWM”), a professional association comprised of state, county and local regulators, and Handbook 44 serves as the basis for specifications and tolerances for weights and measures officials nationally. The latest version for EV charging has been adopted by law in 30 states, and most of these states are currently not expected to begin enforcing the regulations until 2028, although this timeline is subject to change. California adopted its own weights and measures regulations in 2019 and was the first state to begin

enforcing these requirements in 2021 for AC chargers installed on or after January 1, 2021, and in 2023 for DC chargers installed on or after January 1, 2023. AC chargers installed before 2021 are not subject to the regulations until 2031, and DC chargers installed prior to 2023 are not subject to the regulations until 2033. Other states have adopted an older version of Handbook 44 or, like California, have promulgated their own regulations.

Generally, public utilities commissions and state legislatures across the country have determined that EV charging service providers will not be regulated as utilities. While exceptions still exist and individual state determinations are not binding on any other regulator or jurisdiction, they demonstrate a trend in the way states view the EV charging industry. Other jurisdictions are exploring similar reforms. The determination not to regulate the Company as a utility generally frees the Company from being subject to more burdensome regulatory requirements and provides the Company with greater flexibility to set rates, including setting pricing for EV charging on a per-kWh basis across its portfolio of public chargers, subject to restrictions in certain jurisdictions.

Grants and Incentives

EVgo continuously pursues public grants and leverages utility incentives to reduce capital expenditures. EVgo has dedicated and plans to continue to dedicate a variety of internal and external resources to shape, monitor, submit for and utilize available grant and incentive funding for the development of DCFCs on a state, local and national level. EVgo’s network expansion and local build plans are informed partially based on expected timing for and availability of funding of this type. EVgo has received awards for grants and incentives from state energy offices, state departments of transportation, local air districts, and utility rebate and “make-ready” programs.

EVgo has historically benefitted from the availability of federal tax credits under Section 30C of the Code, which effectively subsidizes the cost of placing in service EVgo’s charging stations. The Inflation Reduction Act revised the credit under Section 30C to extend the credit until December 31, 2032, introduce the concept of transferability of such tax credits, expand the credit such that it is capped at $100,000 per item and increase eligibility requirements to require installation of EV charging stations in certain census tracts along with meeting prevailing wage and apprenticeship requirements, among other changes. See Part I, Item 1A, “Risk Factors — Risks Related to the EV Market — The EV market currently benefits from the availability of rebates, tax credits and other financial incentives from governments, utilities and others to offset the purchase or operating cost of EVs and EV charging stations. The reduction, modification or elimination of such benefits could adversely affect EVgo’s financial results.” for further discussion.

EVgo intends to continue to vigorously seek additional grants, rebates, subsidies and incentives as an effective avenue to reduce its capital investment in the promotion, purchase and installation of charging stations where applicable.

Government Regulations to Enhance EV Adoption

The regulations mandated by the National Highway Transit Safety Administration (“NHTSA”)’s Corporate Average Fuel Economy (“CAFE”) standards set the average new vehicle fuel economy, as weighted by sales, that a manufacturer’s fleet must achieve. These standards have been established through Model Year 2026 for light-duty vehicles; however, in September 2021, the Biden Administration proposed to significantly increase these standards for model years 2024-2026 and EVgo expects the administration to set standards for future model years as well. Although EVgo is not a car manufacturer and thus not directly subject to CAFE standards, such standards may still indirectly affect EVgo’s business. The adoption of more stringent federal standards may create further incentives for vehicle manufacturers to increase their EV offerings, which would likely result in increased demand for charging services. Additionally, several states, including California, Colorado, Connecticut, Delaware, Maine, Maryland, Massachusetts, Nevada, New Jersey, New Mexico, Oregon, Pennsylvania, Rhode Island, Vermont, Virginia and Washington D.C., have adopted or are considering adopting bans on the sale of ICE vehicles by 2035.

Waste Handling and Disposal

EVgo is subject to laws and regulations regarding the handling and disposal of hazardous substances and solid wastes, including electronic wastes and batteries. These laws generally regulate the generation, storage, treatment, transportation and disposal of solid and hazardous waste and may impose strict, joint and several liability for the investigation and remediation of areas where hazardous substances may have been released or disposed. For instance, the Comprehensive

Environmental Response, Compensation and Liability Act (“CERCLA”), also known as the superfund law, in the U.S. and comparable state laws impose liability, without regard to fault or the legality of the original conduct, on certain classes of persons that contributed to the release of a hazardous substance into the environment. These persons include current and prior owners or operators of the site where the release occurred as well as companies that disposed or arranged for the disposal of hazardous substances found at the site. Under CERCLA, these persons may be subject to joint and several strict liability for the costs of cleaning up the hazardous substances that have been released into the environment, for damages to natural resources and for the costs of certain health studies. CERCLA also authorizes the Environmental Protection Agency (the “EPA”) and, in some instances, third parties to act in response to threats to the public health or the environment and to seek to recover from the responsible classes of persons the costs they incur.

The Company may also generate or dispose of solid wastes, which may include hazardous wastes that are subject to the requirements of the Resource Conservation and Recovery Act (“RCRA”) and comparable state statutes. While RCRA regulates both solid and hazardous wastes, it imposes strict requirements on the generation, storage, treatment, transportation and disposal of hazardous wastes. Certain components of EVgo’s charging stations may be excluded from RCRA’s hazardous waste regulations, provided certain requirements are met. However, if these components do not meet all of the established requirements for the exclusion, or if the requirements for the exclusion change, the Company may be required to treat such products as hazardous waste, which are subject to more rigorous and costly disposal requirements. Any such changes in the laws and regulations, or in EVgo’s ability to qualify the materials the Company uses for exclusions under such laws and regulations, could adversely affect EVgo’s operating expenses.

Renewable Energy Markets

As part of EVgo’s business strategy, the Company markets the electricity provided from EVgo’s charging stations as 100% matched with purchases of renewable energy certificates (“RECs”). Any claims EVgo makes to consumers about EVgo’s use of renewable energy are subject to regulation by the Federal Trade Commission (“FTC”). The FTC Green Guides require all non-renewable energy use to be matched with RECs in order to make renewable energy claims and may also require certain statements regarding the sources of renewable energy and related RECs. Failure to comply with such regulations can result in substantial monetary penalties or otherwise impact EVgo’s results of operations. Therefore, the Company purchases certified RECs in order to qualify the electricity the Company distributes through charging stations as renewable energy and will continue to purchase certified RECs in the future to substantiate claims that the electricity provided from EVgo’s charging stations is 100% matched with purchases of renewable energy.

Additionally, as part of EVgo’s business model, the Company projects the number of RECs needed and purchases such RECs to meet this projection. Failure to accurately project EVgo’s REC needs may result in the purchasing of RECs on the spot market in order to maintain compliance with applicable regulations. If material, this may adversely affect EVgo’s business and financial condition.

LCFS Credits

As a charging station owner and operator, EVgo earns regulatory credits, such as Low Carbon Fuel Standard (“LCFS”) credits and other regulatory credits, in states where such programs are enacted currently, including the LCFS Program in California, the Clean Fuels Program in Oregon, and the Clean Fuel Standard in Washington. These credits are generated through charging station operations based on the volume of kWh sold. EVgo earns additional revenue through the sale of these credits to buyers obligated to purchase the credits to comply with the program mandates. In California, EVgo actively seeks to maximize the number of credits generated per kWh of energy sold by sourcing renewable electricity. The availability of such credits depends on continued governmental support for these programs and regulatory frameworks that make it possible for EVgo to participate in these credit markets. In addition to current programs, EVgo is currently monitoring or participating in state level policy activity to promulgate new clean fuels programs in states such as Illinois, Massachusetts, Michigan, Minnesota, New Jersey, New Mexico and New York.

Human Capital Management

EVgo believes that its people are its most important asset. The Company is focused on fostering a diverse workforce with different perspectives, experiences, and backgrounds to encourage innovative and creative ideas, and ultimately lead to collective success.

leadership. The Company uses terms like BIPOC and LGBTQ+, acknowledging their limitations in conveying the multitudes of identity. As language and social beliefs evolve, EVgo commits to evolving with them and mentoring and promoting people within its community whom EVgo values for their hard work, intelligence, and agility in pursuit of its mission. EVgo commits to building a portfolio of vendors that includes minority-owned businesses and to creating initiatives that ensure its employees are seen, heard, and valued. EVgo commits to continue checking in with leadership and employees to see how the Company is doing. And most importantly, EVgo commits to listening with openness. As EVgo aims to rapidly grow as a business, it commits to growing as a community as well.

The Company’s success depends on a diverse staff and inclusive leadership. EVgo believes the only way to achieve its vision of “Electric for All” is to utilize the strength that comes from the richness of diversity. Leading the vision of “Electric for All,” it commits to building and empowering a workplace community that values its members for simply being who they are.

Talent, Attraction, Development and Engagement. From EVgo’s frontline employees to its leadership roles, the Company has maintained a focus on attracting, developing and retaining a robust talent pipeline to remain competitive and to continue to provide its customers with the highest standard of service.

EVgo’s employees grow through a variety of training and development opportunities at all career tracks within the organization. EVgo has an all-employee “EVgo Academy” program that includes Master Classes and training resources such as Udemy. In November 2023, the Company hosted its second company-wide EVgo University event covering in depth facets of its business, including what the Company is doing to enhance the customer experience, and developing team building, including employee communication, collaboration and ownership with focus on how to hold crucial conversations and the importance of after-action reviews. EVgo conducts a semi-annual employee engagement survey in which employees can give input. EVgo also offers tuition reimbursement programs to its employees.

Compensation and Benefits Program. EVgo’s compensation program is designed to attract and reward talented individuals who possess the skills necessary to support the Company’s business objectives, assist in the achievement of its strategic goals and create long-term value for its stockholders. The Company provides employees with compensation packages that include competitive salaries, annual discretionary performance bonuses tied to objectives and key results,

and, for all full-time employees, long-term equity awards tied to time-based vesting conditions. EVgo believes that a compensation program with both short-term and long-term awards provides fair and competitive compensation and aligns employee and stockholder interests, including by incentivizing business and individual performance (pay for performance), motivating based on long-term performance and integrating compensation with its business plans. EVgo participates in a compensation benchmark survey to review the competitiveness of its compensation packages. In addition, the Company offers employees benefits such as hybrid work options, life insurance, comprehensive health plans (medical, dental and vision), flexible paid time off, generous supplemental parental pay, EVgo EV car loaners at company headquarters, discounted charging nationwide, and a 401(k) plan.

ESG Matters

EVgo views ESG as integral to its business strategy and its mission to expedite mass adoption of EVs for everyone. EVgo strives to protect the environment and help tackle climate change, accelerating the transition to clean energy. EVgo is also committed to the promotion of sustainable communities and the promotion of equal access. EVgo believes that excellence in ESG provides a benefit to EVgo’s stakeholders and the communities in which EVgo operates.

Available Information

As soon as reasonably practicable after they are filed electronically with the SEC, EVgo’s annual reports on Form 10-K, quarterly reports on Form 10-Q, current reports on Form 8-K, and amendments to those reports are available without charge on EVgo’s website, investors.evgo.com, which EVgo also uses to announce material information to the public. EVgo is providing the address to EVgo’s website solely for the information of investors. EVgo does not intend the address to be an active link or to otherwise incorporate the contents of the website into this Annual Report.

​

Item 1A. Risk Factors.

In the course of conducting its business operations, EVgo is exposed to a variety of risks, any of which have affected or could materially adversely affect EVgo’s business, financial condition and results of operations. Before you make a decision to buy EVgo’s securities, in addition to the risks and uncertainties discussed above under “Cautionary Statement Regarding Forward-Looking Statements,” you should carefully consider the specific risks set forth herein. If any of these risks actually occurs, EVgo’s business, financial condition, liquidity and results of operations may be harmed. As a result, the market price of EVgo’s securities could decline, possibly significantly or permanently, and you could lose all or part of your investment. Additionally, the risks and uncertainties described in this Annual Report are not the only risks and uncertainties that EVgo faces. Additional risks and uncertainties not presently known to the Company or that EVgo currently believes to be immaterial may become material and may adversely affect EVgo’s business.

Summary of Risk Factors

The following summarizes the risks facing EVgo’s business, all of which are more fully described below. This summary should be read in conjunction with the complete set of Risk Factors below and should not be relied upon as an exhaustive summary of the material risks facing EVgo’s business. The order of presentation is not necessarily indicative of the level of risk that each factor poses to EVgo.

Risks Related to EVgo’s Business

​

Risks Related to the EV Market

Risks Related to EVgo’s Technology, Intellectual Property and Infrastructure

Financial, Tax and Accounting-Related Risks

Risks Related to EVgo’s “Up-C” Structure and the Tax Receivable Agreement

Risks Related to Legal Matters and Regulations

Risks Related to EVgo’s Securities

​

Risk Factors

Risks Related to EVgo’s Business

EVgo is an early-stage growth company with a history of operating losses and expects to incur significant expenses and continuing losses at least for the near- and medium-term.

EVgo has a history of operating losses and negative operating cash flows. As of December 31, 2023, EVgo had $209.1 million of cash, cash equivalents, and restricted cash and working capital of $178.1 million. EVgo’s net cash outflow for the year ended December 31, 2023 was $37.3 million. While EVgo believes EVgo’s cash on hand as of December 31, 2023 is sufficient to meet EVgo’s current working capital and capital expenditure requirements, there can be no assurance that EVgo will be able to achieve and maintain profitability in the future. EVgo’s potential profitability is particularly dependent upon the continued adoption of EVs by consumers, fleet operators and other electric transportation modalities, continued support from regulatory programs and, in each case, the use of EVgo’s chargers, any of which may not occur at the levels EVgo currently anticipates or at all. EVgo may need to raise additional financing through loans, securities offerings or additional investments in order to fund EVgo’s ongoing operations. There is no assurance that EVgo will be able to obtain such additional financing or that EVgo will be able to obtain such additional financing on favorable terms.

EVgo’s growth and success are highly correlated with and thus dependent upon the continuing rapid adoption of and demand for EVs and OEMs’ ability to supply such EVs to the market.

EVgo’s growth is highly dependent upon the continued rapid adoption of EVs by governments, businesses and consumers. The market for EVs is still rapidly evolving, characterized by rapidly changing technologies, increasing consumer choice as it relates to available EV models, their pricing and performance, evolving government regulation and industry standards, changing consumer preferences and behaviors, intensifying levels of concern related to environmental issues and government initiatives related to climate change and the environment generally. EVgo’s revenues are driven in large part by EV drivers’ driving and charging behavior. Potential shifts in behavior may include but are not limited to changes in annual vehicle miles traveled, preferences for urban vs. suburban vs. rural and public vs. private, and DCFC vs. Level 2 charging, demand from rideshare or urban delivery fleets and the emergence of autonomous vehicles and/or new forms of mobility. Although demand for EVs has grown in recent years, there is no guarantee of continuing future demand. Public DC fast charging may not develop as expected and may fail to attract projected market share of total EV charging. If the market for EVs develops more slowly than expected, or if demand for EVs develops more slowly than expected or decreases, EVgo’s growth would be reduced, and EVgo’s business, prospects, financial conditions, and operating results would be harmed. The market for EVs, and ultimately EV charging, could be affected by numerous factors, such as:

In addition, sales of vehicles in the automotive industry can be cyclical, which may affect growth in acceptance of EVs. It is uncertain how macroeconomic factors will impact demand for EVs, particularly because EVs can be more expensive than traditional gasoline-powered vehicles. Furthermore, because fleet operators often make large purchases of EVs, this cyclicality and volatility in the automotive industry may be more pronounced with commercial purchasers, and any significant decline in demand from these customers could reduce demand for EV charging and EVgo’s products and services in particular. Moreover, any legislative or regulatory restrictions on the operation or growth of the autonomous vehicle industry, or curtailed investment in the autonomous vehicle industry, could limit demand for EV charging from operators in the autonomous vehicle industry.

While many global OEMs and several new market entrants have announced plans for new EV models, the lineup of EV models with increasing fast charging needs expected to come to market over the next several years may not materialize in that timeframe or may fail to attract sufficient customer demand. Demand for EVs may also be affected by factors directly impacting automobile prices or the cost of purchasing and operating automobiles, such as sales and financing incentives, prices of raw materials and parts and components, cost of fuel and governmental regulations, including tariffs, import regulations and other taxes. Volatility in demand may lead to lower vehicle unit sales, which may result in reduced demand for EV charging solutions and therefore adversely affect EVgo’s business, financial condition and operating results.

EVgo has recently experienced rapid growth. If EVgo fails to manage growth effectively, EVgo’s business, operating results and financial condition would be adversely affected.

EVgo has experienced rapid growth in recent periods. The expected continued growth and expansion of EVgo’s business may place a significant strain on management, business operations, financial condition and infrastructure and corporate culture.

With continued fast growth, EVgo will be required to continue developing, implementing, and enhancing its information technology systems and internal control over financial reporting and related procedures. The implementation, maintenance, segregation, and improvement of these systems require significant management time, support and cost, and there are inherent risks associated with developing, implementing, improving, and expanding core systems as well as updating current systems, including disruptions to the related areas of business operations. These risks may affect EVgo’s ability to manage its data and inventory, procure parts or supplies or manufacture, sell, deliver and service products, adequately protect its intellectual property or achieve and maintain compliance with, or realize available benefits under, tax laws and other applicable regulations. These risks may also result in data security incidents that may interrupt business operations and allow third parties to obtain unauthorized access to business information or misappropriate funds. EVgo may also face risks to the extent such third parties infiltrate the information technology infrastructure of EVgo’s contractors.

To manage growth in operations and personnel, EVgo will need to continue to enhance EVgo’s operational, financial and management controls and reporting systems and procedures. Failure to manage growth effectively could result in difficulty or delays in attracting new customers, declines in quality or customer satisfaction, increases in costs, difficulties in introducing new products and services or enhancing existing products and services, loss of customers, information security vulnerabilities or other operational difficulties, any of which could adversely affect EVgo’s business performance and operating results. EVgo’s strategy is based on a combination of growth and maintenance of strong performance on EVgo’s existing asset base and any inability to scale, maintain customer experience or manage operations at EVgo’s charging stations may impact EVgo’s growth trajectory.

EVgo is susceptible to risks associated with an increased focus by stakeholders and regulators on climate change, which may adversely affect its business and results of operations.

Climate-related events, including the increasing frequency of extreme weather events and their impact on critical infrastructure in the U.S. and elsewhere, have the potential to disrupt EVgo’s business, its third-party suppliers and the business of its customers and may cause it to experience higher attrition, losses and additional costs to maintain or resume operations. In addition, EVgo’s customers may begin to establish sourcing requirements related to sustainability. As a result, EVgo may receive requests for sustainability related information about its products, business operations and use of sustainable materials, among other data. EVgo’s inability to comply with these and other sustainability requirements in the future could adversely affect sales of and demand for its products. See Part I, Item IA, “Risk Factors — Risks Related to Legal Matters and Regulations — Increasing attention to ESG matters may increase EVgo’s costs of compliance and adversely impact EVgo’s business.”

EVgo’s estimates of market opportunity and forecasts of market growth may prove to be inaccurate.

EVgo’s beliefs about the potential for market growth and wider adoption of EVs are subject to significant uncertainty and are based on assumptions and estimates that may prove to be inaccurate. EVgo’s internal estimates relating to the size and expected growth of the target market, market demand, EV adoption across individual market verticals and use cases, capacity of automotive and battery OEMs and ability of charging infrastructure to address this demand and related pricing may also prove to be inaccurate. In particular, estimates regarding the current and projected market opportunity for public and commercial fast charging and future fast charging throughput or EVgo market share capture are difficult to predict. The estimated addressable market may not materialize in the timeframe of EVgo’s internal projections, if ever, and even if the markets meet the size estimates and growth estimates presented, EVgo’s business could fail to grow at similar rates.

EVgo currently faces competition from a number of companies and expects to face significant competition in the future as the market for EV charging develops.

The EV charging market is relatively new, and EVgo currently faces competition from a number of companies. There are a number of established and emerging EV charging companies operating in the U.S. that pursue various business models that are constantly evolving, including Blink, Borg Warner (formerly Rhombus), BP, ChargePoint, Electrify America, Flo, IoTecha, Shell Recharge Solutions (formerly Greenlots and Volta), Tesla, and Tritium, as well as certain utilities and retailers. Additionally, in 2023, a number of OEMs, including BMW, GM, Honda, Hyundai, Kia, Mercedes-Benz and Stellantis, formed Ionna, a joint venture, for the purpose of building a large EV charging network in North America.

EVgo competes (or, in the future, may compete) with some or all of these companies and other competitors across a number of industry segments, including retail and fleet. The principal competitive factors in the industry include charger count, locations, accessibility and reliability; charger connectivity to EVs and ability to charge all standards; speed of charging relative to expected vehicle dwell times at the location; DCFC network reliability, scale and local density; the software-enabled services offered and overall customer experience; operator brand, track record and reputation; access to equipment vendors, and service providers; and policy incentives and pricing. Competitors may be able to respond more quickly and effectively than EVgo to new or changing opportunities, technologies, standards or customer requirements and may be better equipped to initiate or withstand substantial price competition. Additionally, historically EVgo has generated a significant portion of its revenue from agreements with OEM partners, and the loss of one or more of these OEM partners as a result of such partners investing in their own EV charging networks (or another EV charging network in which they participate) could adversely affect EVgo’s business and results of operations.

In addition, there are other means for charging EVs, which could affect the level of demand for charging at EVgo’s DCFCs. For example, Tesla Inc. (“Tesla”) continues to build out its supercharger network across the U.S. for Tesla vehicles and has opened up a portion of its supercharger network to non-Tesla EV vehicles, which could reduce overall demand for EV charging at other sites, including EVgo’s charging stalls. Also, other companies sell chargers designed for customers seeking to have on-premises EV charging capability as well as for home or workplace charging, which may reduce the demand for fast charging if EV owners find “slow” charging at a workplace, at home, or other parking locations to be sufficient. Municipalities may decide to convert street lighting poles and lampposts to public charging points for EV drivers who rent, have no access to home charging, or park their EVs on the street, potentially reducing EVgo’s serviceable

markets. Retailers, utilities or other Site Hosts or commercial, municipal and federal fleet businesses may opt to become owners and operators of public or private EV fast charging equipment and purchase that equipment and associated management software directly from vendors in the marketplace.

Further, EVgo’s current or potential competitors may be acquired by third parties with greater available resources. As a result, competitors may be able to respond more quickly and effectively than EVgo to new or changing opportunities, technologies, standards or customer requirements and may have the ability to initiate or withstand substantial price competition. In addition, competitors may in the future establish cooperative relationships with vendors of complementary products, technologies or services to increase the availability of their solutions in the marketplace.

The EV charging business may become more competitive, pressuring demand for charging on EVgo’s charging network and therefore EVgo’s network utilization, revenue and margins. Competition is still developing and is expected to increase as the number of EVs sold increases. Barriers to entry in the EV charging market have eroded, and may continue to erode, as a result of government intervention and various support programs, leading to more competitors with a variety of profitability objectives.

Because EVgo is currently dependent upon a limited number of customers and OEM partners, the loss of a significant customer or OEM partner could adversely affect EVgo’s operating results.

Given the nascent stage of the industry, a limited number of contractual commercial customers and OEM partners currently account for a substantial portion of EVgo’s income. For the years ended December 31, 2023 and 2022, one customer represented 45.2% and two customers collectively represented 42.9% of total revenue, respectively. EVgo’s operating projections are currently contingent on EVgo’s performance under EVgo’s commercial contracts. At least in the short term, EVgo expects that a majority of EVgo’s sales outside of the retail customer market will continue to come from a concentrated number of commercial customers and OEM partners. EVgo expects a substantial portion of EVgo’s cash receipts in the near future to be from a limited number of commercial customers and OEM partners and, as a result, will be subject to any risks specific to those entities and the jurisdictions and markets in which they operate, including OEMs’ ability to develop a portfolio of EV models and attract customers for those models and maintain or expand their investments in EVs and EV charging infrastructure. EVgo may be unable to accomplish EVgo’s business plan to diversify and expand EVgo’s customer and OEM partner base by attracting a broad array of customers and OEM partners, which could negatively affect EVgo’s business, results of operations and financial condition.

EVgo’s success and growth depends on EVgo’s ability to develop and maintain relationships with automotive OEM and fleet partners.

The success of EVgo’s business depends on EVgo’s ability to develop and maintain relationships with OEMs, such as GM, Nissan, Tesla and others. These relationships help the Company access new customers and build brand awareness through co-marketing. EVgo may also benefit from promotional programs sponsored by OEMs, such as prepaid charging credits. In some cases, EVgo’s OEM partners have agreed to fund capital expenditures related to the build-out of EVgo’s charger network. For example, GM is providing payments for performance obligations that will help fund the accelerated build-out of 3,250 charger stalls for EVgo’s fast charger network through March 2026. If EVgo fails to develop and maintain relationships with OEMs, or if OEMs opt to partner with competitors rather than the Company, EVgo’s revenues may decline and EVgo’s business may suffer.

EVgo’s revenue growth will also depend in part on EVgo’s ability to increase sales of EVgo’s products and services to fleet operators, including rideshare operators. The electrification of fleets is an emerging market, and fleet operators may not adopt EVs on a widespread basis, operate on the timelines EVgo anticipates or rely on public and/or private fast charging and EVgo’s network. In addition to the factors affecting the growth of the EV market generally, transitioning to an EV fleet can be costly and capital intensive, which could result in slower than anticipated adoption. The sales cycle could also be longer for sales to fleet operators with formal procurement processes. Fleet operators may also require significant additional services and support, and if EVgo is unable to provide such services and support, it may adversely affect EVgo’s ability to attract additional fleet operators as customers.

There can be no certainty that EVgo will be able to identify and contract with suitable additional OEM and fleet partners. To the extent EVgo identifies such partners, EVgo will need to negotiate the terms of a commercial agreement with such partners. There can be no assurance that EVgo will be able to negotiate commercially attractive terms with additional OEM and fleet partners, if at all. EVgo may also be limited in negotiating future commercial agreements by the provisions of EVgo’s existing contracts such as “most-favored nations” clauses. For example, EVgo’s contracts with GM prohibit the Company from entering into agreements for similar programs on terms more favorable than the terms afforded to GM for a limited period of time. See Part I, Item 1, “Business — Customers, Partnerships and Strategic Relationships.”

In addition, EVgo may be unable to maintain successful relationships with EVgo’s OEM and fleet partners. Some of EVgo’s existing agreements require the Company to meet specified performance criteria. If EVgo fails to meet such criteria, the agreements could be terminated, and EVgo may be obligated to pay significant penalties or other damages. If an agreement is terminated, any support payments pursuant to the contract would cease. Finally, if OEMs observe the Company failing to meet EVgo’s specified performance criteria, EVgo’s reputation may be damaged, and it may become more difficult for the Company to establish new partnerships with OEMs. Any failure to attract and retain OEMs or fleet operators as customers in the future would adversely affect EVgo’s business and results of operations.

EVgo will be required to install a substantial number of chargers under EVgo’s agreement with GM. If EVgo does not meet EVgo’s obligations under this agreement, EVgo may not be entitled to payments from GM and may be required to pay liquidated damages, which may be significant.

Pursuant to the GM Agreement, EVgo is required to meet certain quarterly milestones measured by the number of charger stalls installed and GM is required to make certain payments based on charger stalls installed. Under the GM Agreement, EVgo is required to install a total of 3,250 charger stalls by March 31, 2026. The GM Agreement calls for a year-over-year increase in annual charger stall additions from 2022 to 2024, flattening in 2025, before declining in the first quarter of 2026. Meeting these milestones will require additional funds beyond the amounts committed by GM and EVgo may face delays in construction, commissioning or aspects of installation of the charger stalls EVgo is obligated to develop. In addition, EVgo is required to maintain network availability across the GM network (i.e., the percentage of time a charger stall is operational and available on the network) of at least 95% across the GM network.

The GM Agreement is subject to early termination in certain circumstances, including in the event EVgo fails to meet the quarterly charger stall-installation milestones or fails to maintain the specified level of network availability. In the event EVgo fails to meet a charger stall-installation milestone or maintain the required network availability in a calendar quarter, GM has the right to provide EVgo with a notice of such deficiency within 30 days of the end of the quarter. If the same deficiency still exists at the end of the quarter immediately following the quarter for which a deficiency notification was delivered, GM may immediately terminate the agreement and seek pre-agreed liquidated damages of up to $15.0 million.

EVgo may not meet the charger stall-installation milestones under the GM Agreement in the future, particularly as a consequence of delays in permitting, commissioning and utility interconnection, as well as delays related to industry and regulatory adaptation to the requirements of high-powered charger installation including slower than expected third-party approvals of certain site acquisitions and site plans by utilities and land owners, and supply chain issues. As of February 15, 2024, there were approximately 1,028 charger stalls in the active engineering and construction development pipeline, of which approximately 964 charger stalls had been approved by GM. As of February 15, 2024, EVgo had approximately 82 charger stalls left to install in order to meet its charger stall-installation milestone for the quarter ending March 31, 2024. If EVgo does not meet its charger stall-installation milestone in any period, GM will have the right, if it so chooses, to send EVgo a charger stall count breach notice, which would trigger a cure period. Under the terms of the GM Agreement, GM and EVgo can agree to adjust quarterly charger stall installation milestones from time to time, provided the quarterly targets for an applicable calendar year must equal the annual target for such year. Going forward, it is uncertain if these, or other potential issues in the procurement, installation, or energization of chargers, will be resolved in a timely fashion.

Nissan has the right to terminate its agreement with the Company in certain circumstances. Additionally, EVgo may be subject to monetary penalties if EVgo is unable to fulfill EVgo’s obligations under EVgo’s agreements with Nissan.

EVgo executed an agreement with Nissan North America, Inc. (“Nissan”) in June 2019 (the “Nissan Agreement”) that provides for joint marketing activities, charging credit programs for purchasers or lessees of Nissan EVs, and a capital-

build program. The Nissan Agreement has been amended several times to, among other things, adjust the allocation of the value of unused charging credits and to provide new offerings for purchasers or lessees of certain Nissan EV models. Under the joint-marketing activities provisions of the Nissan Agreement, EVgo was obligated to spend a specified amount annually on joint-marketing activities that were mutually agreed-upon with Nissan until March 1, 2024. Under the charging credit program provisions in the Nissan Agreement, credits for charging are allocated to purchasers or lessees of Nissan EVs, and such purchasers or lessees are permitted to charge their EV for 12 months at no charge to the participant, up to the amount of the charging credit allocated to such participant or on an unlimited basis, depending on the model of Nissan EV purchased or leased. In the event a participant does not use the entire amount of the allocated charging credit or if the annual charging credit pool is not exhausted within a specific period, a portion of the remaining dollar value of such credit rolls over to subsequent periods, and a portion is retained by the Company. For Nissan EV purchasers or lessees receiving unlimited charging, the Company receives an upfront activation fee for each purchaser or lessee as well as a usage-based fee. The capital-build program provided for in the Nissan Agreement requires the Company to install, operate and maintain public, high-power dual-standard chargers in specified markets pursuant to a schedule that outlines the build timelines for the chargers to be constructed (the “Build Schedule”). If the Company fails to meet its Build Schedule obligations, Nissan may invoke a penalty of up to $70,000 per delayed site beyond a designated cure period, which could result in an adjustment to the consideration received by the Company under the Nissan Agreement. EVgo and Nissan previously agreed to amend the Nissan Agreement to extend the installation deadlines under the Build Schedule by up to 12 months, and Nissan has waived penalties for installation delays relating to program year one.

EVgo’s ability to meet its Build Schedule obligations may be impacted by delays in permitting, commissioning and utility interconnection, as well as delays related to industry and regulatory adaptation to the requirements of high-powered charger installation, including slower than expected third-party approvals of certain site acquisitions and site plans by utilities and landowners, and supply chain issues.

Pursuant to the Nissan Agreement, as modified by the aforementioned extensions and other amendments, EVgo is required to install an aggregate of 210 chargers by February 28, 2025. As of February 29, 2024, EVgo had installed a total of 188 chargers at 73 sites and was required to install an additional 22 chargers at up to 5 sites by February 28, 2025.

EVgo will be required to install a substantial number of chargers under EVgo’s agreement with the Pilot Company and GM. If EVgo does not meet EVgo’s obligations under this agreement, EVgo may not be entitled to payments from the Pilot Company and may be required to pay liquidated damages, which may be significant.

Pursuant to the Pilot Infrastructure Agreement, EVgo is required to meet certain milestones over two biennial periods measured by the number of chargers installed and charger sites serviced, and the Pilot Company is required to make certain payments each month based on the progress of construction at each charger site and for each charger procured. Under the Pilot Infrastructure Agreement, EVgo is required to install approximately 500 chargers at 300 charger sites during the first two-year period and will be required to install approximately 500 chargers at approximately 200 to 250 additional charger sites during the second two-year period. EVgo may not be able to meet the charger installation milestones and may be subject to liquidated damages, modifications to the Pilot Infrastructure Agreement or termination of the Pilot Infrastructure Agreement.

Subject to certain excusable events, if EVgo is unable to meet its charger installation obligations in either of the two biennial periods, the Pilot Company may be entitled to liquidated damages. Furthermore, depending on the length of the delay, the Pilot Company may remove the charger site from the portfolio without designating a replacement charger site.

The Pilot Infrastructure Agreement is subject to early termination for several reasons including: (a) at the Pilot Company’s election after 1,000 charging stalls have been completed, subject to the delivery of certain payments to EVgo, (b) the inability of EVgo to secure certain charger types in specified circumstances and (c) a material increase in the price of chargers due to a change in law.

EVgo is committed to purchasing a large number of chargers under the Delta Charger Supply Agreement and Purchase Order, which will require significant capital expenditures, some of which may not be immediately offset by payment by EVgo’s counterparty under the Pilot Infrastructure Agreement.

EVgo entered into the Delta Charger Supply Agreement and Purchase Order in order to meet the charger requirements of the Pilot Infrastructure Agreement. Pursuant to the Delta Charger Supply Agreement and Purchase Order, EVgo will purchase a minimum of 1,000 chargers (which will enable the construction of 2,000 stalls) from Delta over a period of four years with the option, at EVgo’s election, to increase the number of chargers purchased to 1,100. The Purchase Order was amended in August 2023 to provide for certain Delta chargers to be manufactured in Delta’s new facility in Plano, Texas rather than in Taiwan.

If the counterparty under the Pilot Infrastructure Agreement does not meet its obligation to pay for chargers, or if the Pilot Infrastructure Agreement is otherwise terminated, EVgo’s cash flows may be negatively impacted by its obligation to continue to purchase chargers from Delta under the Purchase Order.

Additionally, EVgo depends on a limited number of vendors for charging equipment, including Delta. The inability of Delta to fulfill its requirements under the Delta Charger Supply Agreement and Purchase Order will require EVgo to find an alternative supplier in order to meet its commitments under the Pilot Infrastructure Agreement which may not be available or may be available at significantly higher cost.

EVgo relies on a limited number of vendors for EVgo’s charging equipment and related support services. A loss of any of these partners could negatively affect EVgo’s business.

EVgo relies on a limited number of vendors for design, testing and manufacturing of charging equipment which at this stage of the industry is unique to each supplier and thus singularly sourced with respect to components as well as aftermarket maintenance and warranty services. For the year ended December 31, 2023, one vendor provided 76.9% of EVgo’s total charging equipment. For the year ended December 31, 2022, four vendors collectively provided 88.8% of EVgo’s total charging equipment. This reliance on a limited number of vendors increases EVgo’s risks, since EVgo does not currently have proven reliable alternative or replacement vendors beyond these key parties. In the event of production interruptions or supply chain disruptions including but not limited to reduced availability of certain key components such as semiconductors, EVgo may not be able to take advantage of increased production from other sources or develop alternate or secondary vendors without incurring material additional costs and substantial delays. See Part I, Item IA, “Risk Factors — Disruptions in EVgo’s supply chain could adversely affect EVgo’s business.” Thus, EVgo’s business could be adversely affected if one or more of EVgo’s vendors is impacted by any interruption at a particular location or is acquired or impacted by liquidity issues.

As the demand for public fast charging increases, charging equipment vendors may not be able to dedicate sufficient supply chain, production, or sales channel capacity to keep up with the required pace of charging infrastructure expansion. In addition, as the EV market grows, the industry may be exposed to deteriorating design requirements, undetected faults or the erosion of testing standards by charging equipment and component suppliers, which may adversely impact the performance, reliability and lifecycle cost of the chargers. If EVgo or EVgo’s suppliers experience a significant increase in demand, or if EVgo needs to replace an existing supplier, EVgo may not be able to supplement service or replace the supplier on acceptable terms, which may undermine EVgo’s ability to install chargers in a timely manner. For example, it may take a significant amount of time to identify a vendor that has the capability and resources to supply and/or service charging equipment in sufficient volumes. Identifying and approving suitable vendors could be an extensive process that requires the Company to become satisfied with their quality control, technical capabilities, responsiveness and service, financial stability, regulatory compliance and labor and other ethical practices. Accordingly, a loss of any significant vendor could have an adverse effect on EVgo’s business, financial condition and operating results.

As the federal government and Congress require that charging equipment be manufactured in the U.S. in order to access federal financial support or secure contracts with the federal government, EVgo may have to source equipment from alternative vendors or work with current vendors to develop manufacturing capacity in the U.S. to participate in the covered federal programs.

EVgo’s business is subject to risks associated with construction, cost overruns and delays and other contingencies that may arise in the course of completing installations, and such risks may increase in the future as EVgo expands the scope of such services with other parties.

Charger installation and construction is typically performed by third-party contractors managed by the Company. The installation and construction of charging stations at a particular site is generally subject to oversight and regulation in accordance with state and local laws and ordinances relating to building codes, safety, environmental protection and related matters and typically requires local utility cooperation in design and interconnection request approval and commissioning, as well as various local and other governmental approvals and permits that vary by jurisdiction. In addition, building codes, accessibility requirements, utility interconnect specifications, review, approval or study lead time or regulations may hinder EV charger installation and construction because they end up costing the developer or installer more in order to meet the code requirements. In addition, increased demand for the components necessary to install and construct charging stations could lead to higher installed costs. Meaningful delays or cost overruns caused by EVgo’s vendor supply chains, contractors, utility upgrades scope and delays, or inability of local utilities and approving agencies to cope with heightened levels of activity, may impact EVgo’s ability to satisfy the requirements under the Build Schedule and EVgo’s other contractual commitments, and may impact revenue recognition in certain cases and/or impact EVgo’s relationships, any of which could impact EVgo’s business and profitability, pace of growth and prospects. For example, the installation of charger stalls under the GM Agreement have required significant utility upgrades to accommodate the higher capacity chargers. EVgo has experienced significant delays in these upgrades, which have in turn caused delays in the construction of the chargers pursuant to the GM Agreement. The Company expects utility-related delays to continue as the industry continues to adapt to the requirements of high-powered charger installation. If these delays continue or worsen, EVgo may not meet the charger-installation milestones under the GM Agreement or its other contractual commitments under agreements with other third parties. See Part I, Item IA, “Risk Factors — EVgo will be required to install a substantial number of chargers under EVgo’s agreement with GM. If EVgo does not meet EVgo’s obligations under this agreement, EVgo may not be entitled to payments from GM and may be required to pay liquidated damages, which may be significant” and Part I, Item IA, “Risk Factors — EVgo will be required to install a substantial number of charger stalls under EVgo’s agreement with the Pilot Company and GM. If EVgo does not meet EVgo’s obligations under this agreement, EVgo may not be entitled to payments from the Pilot Company and may be required to pay liquidated damages, which may be significant.”

Working with contractors may require the Company to obtain licenses or require EVgo or EVgo’s customers to comply with additional rules, working conditions and other union requirements, which can add costs and complexity to an installation and construction project. If these contractors are unable to provide timely, thorough and quality installation-related services, EVgo could fall behind EVgo’s construction schedules or cause customers to become dissatisfied with the solutions EVgo offers. As the demand for public fast charging increases and qualification requirements for contractors become more stringent, EVgo may encounter shortages in the number of qualified contractors available to complete all of EVgo’s desired installations. If EVgo fails to timely pay EVgo’s contractors, they may file liens against EVgo’s Site Hosts’ properties, which EVgo is required to remove.

In order to receive certain incentives such as funding under the National Electric Vehicle Infrastructure Formula Program (“NEVI”) and tax credits in connection with the alternative fuel vehicle refueling property credit under Section 30C of the Code, EVgo and EVgo’s customers are required to comply with certain requirements of such programs, which may include payment of prevailing wages, apprenticeship programs and “Buy America” obligations. If EVgo and its contractors are unable to comply with the applicable program requirements, EVgo and its customers may lose the benefit of the applicable incentive program and may be subject to funding clawbacks or other penalties.

EVgo’s business model is predicated on the presence of qualified and capable electrical and civil contractors and subcontractors in the new markets EVgo intends to enter. There is no guarantee that there will be an adequate supply of such partners. A shortage in the number of qualified contractors may impact the viability of the business plan, increase risks related to the quality of work performed and increase costs if outside contractors are brought into a new market.

In addition, EVgo’s network expansion plan relies on EVgo’s site development efforts and EVgo’s business is exposed to risks associated with receiving site control and access necessary for the construction of the charging station and operation of the charging equipment, electrical interconnection and power supply at identified locations sufficient to host chargers on a timely basis. EVgo generally does not own the land at the charging sites and relies on site licenses with Site Hosts

that convey the right to build, own and operate the charging equipment on the site. EVgo may not be able to renew the site licenses or retain site control. The process of establishing or extending site control and access could take longer or become more competitive. As the EV market grows, competition for premium sites may intensify, the power distribution grid may require upgrading, and electrical interconnection with local utilities may become more competitive, all of which may lead to delays in construction and/or commissioning. As a result, EVgo may be exposed to increased interconnection costs and utility fees, as well as delays, which may slow the pace of EVgo’s network expansion.

Disruptions in EVgo’s supply chain could adversely affect EVgo’s business.

The conflict between Russia and Ukraine and an escalation of tensions and conflict in Israel and the broader Middle East region could lead to disruption, instability and volatility in global markets and industries that could negatively impact EVgo’s supply chain. The U.S. government and other governments have already imposed severe sanctions and export controls against Russia and Russian interests and may impose additional sanctions and controls. The impact of these measures, as well as potential responses to them by Russia, could adversely affect EVgo’s supply chain, which, in turn, could affect EVgo’s business and operating results.

Additionally, Delta is headquartered in Taiwan, and EVgo’s ability to receive sufficient supplies of Delta chargers, components and parts could be adversely affected by events such as natural disasters in Taiwan, including earthquakes, drought and typhoons, escalations of tensions between the People’s Republic of China and Taiwan, including resulting from the People’s Republic of China’s military exercises around Taiwan, political unrest, trade restrictions or war.

If EVgo is unable to attract and retain key employees and hire qualified management, technical, engineering, financial, legal, sales, marketing and business development personnel, EVgo’s ability to compete and successfully grow EVgo’s business and customer base could be harmed.

EVgo’s success depends, in part, on EVgo’s continuing ability to identify, hire, attract, train and develop and retain highly qualified personnel. The inability to do so effectively could adversely affect EVgo’s business. Competition for employees can be intense and the ability to attract, hire and retain them depends on EVgo’s ability to provide meaningful work at competitive compensation. EVgo may not be able to attract, assimilate, develop or retain qualified personnel in the future and failure to do so could adversely affect EVgo’s business, including the execution of EVgo’s growth business strategy.

EVgo may need to raise additional funds, and these funds may not be available when needed or may only be available on unfavorable terms, which could impact the Company’s ability to fund its operations, its growth and the build-out of the Company’s network.

EVgo may need to raise additional capital in the future to fund its operations, further scale EVgo’s business and expand EVgo’s charging network. EVgo may raise additional funds through the issuance of equity, equity-related or debt securities, through obtaining credit from government or financial institutions or through grant funding. EVgo cannot be certain that additional funds or incentives will be available on favorable terms when required, or at all, or that EVgo will be able to capture expected grant funding under various existing and new state and local programs in the future. Recent increases in interest rates could increase the cost of capital, and it is not clear if interest rates will continue to rise or remain elevated in future periods.

If EVgo cannot raise additional funds when needed, EVgo’s financial condition, results of operations, business and prospects could be materially and adversely affected. If EVgo raises funds through the issuance of debt securities or through loan arrangements, the terms for such securities or arrangements could require significant interest payments, contain covenants that restrict EVgo’s business, or other unfavorable terms and rank senior to the interests held by EVgo’s stockholders. In addition, to the extent EVgo raises funds through the sale of additional equity securities, the market price of EVgo’s Class A common stock could be adversely affected and EVgo’s stockholders would experience dilution. See Part I, Item IA, “Risk Factors — Risks Related to EVgo’s Securities — The market price of EVgo’s Class A common stock could be adversely affected by, and EVgo’s stockholders may experience dilution as a result of, sales of substantial amounts of Class A common stock in the public or private markets, including sales by the Company, EVgo Holdings or other large holders.”

EVgo’s business is subject to risks associated with natural disasters, including earthquakes, hurricanes, wildfires and other severe weather events, which could be impacted by the effects of climate change. An earthquake, a wildfire, a major hurricane or other types of disasters or resource shortages, including public safety power shut-offs that have occurred and will continue to occur in California or other states, could disrupt and harm EVgo’s operations and those of EVgo’s customers.

Many of EVgo’s facilities are located in California, an active earthquake zone, and Florida and Texas, areas susceptible to hurricanes. Additionally, EVgo has significant operations in a number of areas, including Los Angeles and San Francisco, that are projected to be vulnerable to future water scarcity and sea level rise due to climate change. The occurrence of a natural disaster such as an earthquake, hurricane, drought, flood, fire, localized extended outages of critical utilities or transportation systems, or any critical resource shortages could cause a significant interruption in EVgo’s business, damage or destroy EVgo’s facilities or inventory and cause the Company to incur significant costs, any of which could harm EVgo’s business, financial condition and results of operations. Climate change may also result in various physical risks, such as the increased frequency or intensity of extreme weather events or changes in meteorological and hydrological patterns that could adversely impact EVgo’s business. Such physical risks may result in damage to EVgo’s facilities or otherwise adversely impact operations. The insurance EVgo maintains against fires, earthquakes, hurricanes and other disasters and damage may not be adequate to cover losses in any particular case.

In addition, rolling public safety power shut offs in California or other states can affect throughput and/or user acceptance of EVs, as charging may be unavailable at the desired times, or at all during these events. These shut offs could also affect the ability of fleet operators to charge their EVs, which, for example, could adversely affect transportation schedules or any service level agreements to which either EVgo or the fleet operator may be a party. Additionally, extended patterns of extreme cold weather have caused and may in the future cause, owners of EVs to experience reduced charging speeds and driving ranges. If any of these events occur and/or persist, the demand for EVs could decline, which would result in reduced demand for charging.

Further, severe natural disasters could affect vendors’ data centers in a temporary or longer-term fashion which would adversely affect EVgo’s ability to operate EVgo’s network.

EVgo’s charging stations are often located in areas that are publicly accessible and may be exposed to vandalism or misuse by customers or other individuals, which would increase EVgo’s replacement and maintenance costs.

EVgo’s public chargers may be exposed to vandalism or misuse by customers and other individuals, increasing wear and tear of the charging equipment. Such damage could shorten the usable lifespan of the chargers and require the Company to increase its spending on replacement, maintenance and insurance costs and could result in site hosts reconsidering the value of hosting EVgo’s charging stations at their sites. In addition, the cost of any such damage may not be covered by EVgo’s insurance in full or at all and, in the event of repeated damage to EVgo’s charging equipment, EVgo’s insurance premiums and deductibles could increase and it could be subject to additional insurance costs or may not be able to obtain insurance at all, any of which could have an adverse effect on its business.

EVgo is dependent upon the availability of electricity at EVgo’s current and future charging stations. Cost increases, delays and/or other restrictions on the availability of electricity would adversely affect EVgo’s business and results of EVgo’s operations.

The operation and development of EVgo’s charging stations is dependent upon the availability of electricity, which is beyond EVgo’s control. EVgo’s charging stations are affected by problems accessing electricity sources, such as planned or unplanned power outages. In recent years, shortages of electricity have resulted in increased costs to users and interruptions in service. In particular, California has experienced rolling blackouts due to excessive demands on the electrical grid or as precautionary measures against the risk of wildfire. Similarly, Texas has experienced failures in its electrical grid due to severe weather. In the event of a power outage, EVgo will be dependent on the utility company and in some cases the Site Host, to restore power. Any prolonged power outage could adversely affect customer experience and EVgo’s business and results of operations.

Changes in utility electricity pricing or new and restrictive constructs from regulations applicable to pricing may adversely impact future operating results. Utility rates may change in a way that adversely affects fast charging or in a way

that may limit EVgo’s ability to access certain beneficial rate schedules. In addition, utilities or other regulated entities with monopoly power may receive authority to provide charging services that result in an anti-competitive advantage relative to the Company and other private sector operators.

Some of EVgo’s business objectives are dependent upon the purchase of renewable energy certificates, and an increase in the cost of such certificates may adversely impact EVgo’s business and results of operations.

As part of EVgo’s business strategy, EVgo markets the electricity provided from EVgo’s charging stations as 100% matched with purchases of RECs. EVgo purchases various RECs in order to qualify the electricity that EVgo distributes through its charging stations as renewable. Several states have passed renewable energy portfolio standards, which set a minimum percentage of energy that must be generated from renewable sources. These standards may require utilities or load serving entities to acquire RECs annually in order to demonstrate their compliance. Other regulations may also impact the supply of and demand for, such RECs. While higher renewable energy portfolio standards may also increase the amount of renewable energy available, EVgo cannot predict the impact such regulations may have on the price or availability of RECs. If EVgo is unable to purchase a sufficient number of RECs, EVgo may be unable to achieve this objective, which may negatively impact EVgo’s reputation in the marketplace. If the cost of RECs increases, EVgo may be unable to fully pass the higher cost of RECs through to EVgo’s customers and increases in the price of RECs may decrease EVgo’s results of operations.

If EVgo fails to offer high-quality support to Site Hosts or drivers or fails to maintain high charger availability and strong user experience, EVgo’s business and reputation will suffer.

Once EVgo’s charging stations are installed, Site Hosts and drivers rely on the Company to provide maintenance services to resolve any issues that might arise in the future. Rapid and high-quality customer and equipment support is important so drivers can receive reliable charging for their EVs. The importance of high-quality customer and equipment support will increase as EVgo seeks to expand EVgo’s business and pursue new customers and geographies. If EVgo does not quickly resolve issues and provide effective support, EVgo’s ability to retain customers or sell additional products and services to existing customers could suffer, and EVgo’s brand and reputation could be harmed. EVgo has limited experience with certain of its charging equipment. While EVgo conducts extensive testing on all new equipment prior to deployment, its assumptions regarding the durability and reliability of its charging equipment could prove to be materially different from the actual performance of such equipment, causing the Company to incur substantial expense to repair or replace defective equipment in the future. Any widespread or persistent equipment failures could damage EVgo’s market reputation, cause its sales and charging revenue to decline, require EVgo to repair or replace the defective equipment, and increase EVgo’s maintenance costs, any of which could have a material adverse effect on EVgo’s business and results of operations.

Our systems are susceptible to various forms of cyber threats, including computer malware, viruses, ransomware, hacking attempts, phishing attacks and other network disruptions. These incidents have the potential to lead to security and privacy breaches, loss of proprietary information and interruptions or delays in EVgo’s services and operations, any of which could significantly harm EVgo’s business.

From time to time, EVgo has experienced cyber attacks on its information technology infrastructure and systems. While EVgo believes such attacks have been unsuccessful against EVgo to-date, computer malware, viruses, physical or electronic break-ins and similar disruptions could lead to interruptions and delays in EVgo’s services and operations and loss, access, disclosure, alteration, destruction, misuse or theft of data, including confidential, proprietary or personal information. Computer malware, viruses, ransomware, hacking, phishing attacks and denial-of-service attacks against online networks have become more prevalent and may occur on EVgo’s systems or the systems of EVgo’s vendors, suppliers or service providers and other third parties. EVgo’s business may be subject to heightened risks of cyber intrusion as nation-state hackers and other hackers use ransomware attacks seeking to disable critical infrastructure and extort companies for ransom payments. Cybersecurity organizations in many countries have published warnings of increased cybersecurity threats to U.S. businesses, and external events, like the conflict between Russia and Ukraine or conflicts in the Middle East, may increase the likelihood of cybersecurity attacks, particularly directed at energy, fueling or infrastructure service providers.

Any such events could harm EVgo’s business, impact EVgo’s customers, introduce liability to data subjects, result in the misappropriation of funds, be expensive to remedy, result in fines, penalties or other liabilities and damage EVgo’s reputation or brand. Additionally, a number of legislative and regulatory bodies have adopted notification and other requirements in the event of a cybersecurity or data breach incident. Complying with such numerous and complex regulations in the event of unauthorized access would be expensive and difficult, and failure to comply with these regulations could subject EVgo to regulatory scrutiny and additional liability.

Insurance may not be sufficient to cover significant expenses, losses and liability related to cyber-attacks, security breaches and incidents, or other similar disruptions. EVgo cannot be certain that its coverage will be adequate for liabilities actually incurred, that insurance will continue to be available to it on economically reasonable terms, or at all, or that any insurer will not deny coverage as to any future claim. The successful assertion of one or more large claims against EVgo that exceed available insurance coverage, or the occurrence of changes in EVgo’s insurance policies, including premium increases or the imposition of large deductible or co-insurance requirements, could have a material adverse effect on EVgo’s business, including its financial condition, operating results, and reputation.

Even with the security measures implemented by the Company, such as managed security services that are designed to detect and protect against cyber-attacks and similar disruptions and any additional measures EVgo may implement or adopt in the future, EVgo’s facilities and systems and those of EVgo’s third-party service providers could be vulnerable to security breaches, computer viruses, lost or misplaced data, programming errors, scams, burglary, human errors, acts of vandalism, or other events. Efforts to prevent cyberattacks and similar disruptions are expensive to implement and, as the regulatory framework for data privacy and security worldwide continues to evolve and develop, EVgo may incur additional significant costs to comply with new or existing laws, regulations and other obligations, and EVgo may not be able to cause the implementation or enforcement of such preventions or compliance with such laws and regulations with respect to EVgo’s third-party vendors. Though it is difficult to determine what, if any, harm may directly result from any specific interruption or attack, an inability to maintain performance, reliability, security and availability of systems and technical infrastructure may, in addition to other losses, harm EVgo’s reputation, brand and ability to attract customers.

EVgo and its third-party vendors have previously experienced and may in the future experience, service disruptions, outages and other performance problems due to a variety of factors, including infrastructure changes, third-party service providers, human or software errors and capacity constraints. EVgo relies on data carrier networks to support reliable operation, management and maintenance of EVgo’s charger network, charging session management, driver authentication and payment processing, all of which depend on reliable connections with wireless communications networks. As a result, EVgo’s operations depend on a handful of public carriers and are exposed to disruptions related to network outages and other communications issues on the carrier networks. See Part I, Item IA, “Risk Factors — A failure of service by one or more of EVgo’s key vendors, including third-party providers of software, technology, applications or communication services that EVgo relies on, could adversely affect EVgo’s business and reputation.” If EVgo’s services are unavailable when users attempt to access them, they may seek other services, which could reduce demand for EVgo’s solutions from customers.

There are several factors ranging from human error to data corruption that could materially impact the efficacy of any processes and procedures designed to enable the Company to recover from a disaster or catastrophe, including by lengthening the time services are partially or fully unavailable to customers and users. It may be difficult or impossible to perform some or all recovery steps and continue normal business operations due to the nature of a particular cyber-attack, disaster or catastrophe or other disruption, especially during peak periods, which could cause additional reputational damages, or loss of revenues, any of which would adversely affect EVgo’s business and financial results.

A failure of service by one or more of EVgo’s key vendors, including third-party providers of software, technology, applications or communication services that EVgo relies on, could adversely affect EVgo’s business and reputation.

EVgo relies on a limited number of third parties, including providers of software, technology and communications services and credit card processors, for the effective operation of its charging network, software platform and mobile applications, for the timely and accurate collection of revenue, and for compliance with certain laws and regulations, such as consumer privacy protections. A failure or limitation of service or available capacity by any of these third-party providers could adversely affect EVgo’s business and reputation.

For example, EVgo is dependent on the interoperability of EVgo’s mobile applications with popular mobile operating systems that EVgo does not control, such as Google’s Android and Apple’s iOS, and any changes in such systems that degrade EVgo’s products’ functionality or give preferential treatment to competitive products could adversely affect the usage of EVgo’s applications on mobile devices. Additionally, in order to deliver high quality mobile products, it is important that EVgo’s products work well with a range of mobile technologies, systems, networks and standards that EVgo does not control. EVgo may not be successful in developing or maintaining relationships with key participants in these industries or in developing products that operate effectively with these technologies, systems, networks or standards.

In addition, a significant portion of EVgo’s software platform depends on EVgo’s partnership with Driivz, an EV charging management platform. If for any reason Driivz is unable to effectively support EVgo’s software platform, EVgo’s business could be adversely impacted. For example, Driivz is headquartered in Israel, and any escalation of tensions or conflict in or involving Israel could lead to disruptions in the services provided by Driivz to the Company, which could adversely impact EVgo’s business. Furthermore, if for any reason EVgo is no longer able to maintain its partnership with Driivz, EVgo may face a material challenge in efficiently transitioning EVgo’s software offering.

In addition, EVgo currently serves customers from third-party data center facilities operated by Amazon Web Services and Google, as well as others. All of EVgo’s services are housed in third-party data centers operated in the U.S., and EVgo employs geographically distributed, redundant back-up data centers for all services. Any outage or failure of such data centers could negatively affect EVgo’s product connectivity and performance. EVgo’s primary environments are operated by Google and Amazon, and any interruptions of these primary and backup data centers could negatively affect EVgo’s product connectivity and performance. Furthermore, EVgo depends on connectivity from EVgo’s charging stations to EVgo’s data centers through cellular service and virtual private networking providers, such as AT&T and Verizon. Any incident affecting a data center facility’s or cellular and/or virtual private networking services provider’s infrastructure or operations, whether caused by fire, flood, storm, earthquake, power loss, telecommunications failures, breach of security protocols, computer viruses and disabling devices, failure of access control mechanisms, natural disasters, war, criminal act, military actions, terrorist attacks and other similar events could negatively affect the use, functionality or availability of EVgo’s services.

Any damage to, or failure of, EVgo’s systems, or those of EVgo’s third-party providers, could interrupt or hinder the use or functionality of EVgo’s services, including EVgo’s subscription services. Impairment of or interruptions in EVgo’s services may reduce revenue, subject the Company to claims and litigation, cause customers to terminate their subscriptions and adversely affect renewal rates and EVgo’s ability to attract new customers. EVgo’s business could also be harmed if customers and potential customers believe EVgo’s products and services are unreliable.

EVgo is subject to risks associated with integrating the PlugShare acquisition, and should EVgo pursue additional acquisitions in the future, EVgo would be subject to risks associated with completing and integrating such acquisitions.

On July 9, 2021, EVgo acquired PlugShare for $25 million in cash, including repayment of $3 million of indebtedness. PlugShare is an EV cloud-based data solution provider formed in 2009 and focused on EV app development, market research, data licensing, reporting and advertising. EVgo continues to be subject to risks with fully integrating the PlugShare personnel as well as the technology platforms acquired.

EVgo may acquire additional assets, products, technologies or businesses that are complementary to EVgo’s existing business and strategic direction. The process of identifying and consummating acquisitions and the subsequent integration of new assets and businesses into EVgo’s own business and operations would require attention from management and could result in a diversion of resources from EVgo’s existing business, which in turn could have an adverse effect on EVgo’s operations. Acquired assets or businesses may not generate the expected financial results. Acquisitions could also result in the use of cash, potentially dilutive issuances of equity securities or securities convertible into equity securities, the occurrence of goodwill impairment charges, amortization expenses for other intangible assets and exposure to potential unknown liabilities of the acquired business. Moreover, the costs of identifying and consummating acquisitions may be significant. Failure to successfully identify, complete, manage and integrate acquisitions could materially and adversely affect EVgo’s business, financial condition and results of operations.

Risks Related to the EV Market

Changes to fuel economy standards or the success of alternative fuels may negatively impact the EV market and thus the demand for EVgo’s products and services.

Regulatory initiatives that required an increase in the mileage capabilities of cars and consumption of renewable transportation fuels, such as ethanol and biodiesel, have helped increase consumer acceptance of EVs and other alternative vehicles. However, the EV fueling model is different from gasoline and other fuel models, requiring behavior changes and education of businesses, consumers, regulatory bodies, local utilities and other stakeholders. Further developments in and improvements in the affordability of, alternative technologies, such as renewable diesel, biodiesel, ethanol, hydrogen fuel cells or compressed natural gas, proliferation of hybrid powertrains involving such alternative fuels, or improvements in the fuel economy of ICE vehicles, whether as the result of regulation or otherwise, may materially and adversely affect demand for EVs and EV charging stations in some market verticals. Regulatory bodies may also adopt rules that substantially favor certain alternatives to petroleum-based propulsion over others, which may not necessarily be EVs. Local jurisdictions may also impose restrictions on urban driving due to congestion, which may prioritize and accelerate micromobility trends and slow EV adoption growth. If any of the above cause or contribute to automakers reducing the availability of EV models or cause or contribute to consumers or businesses no longer purchasing EVs or purchasing fewer of them, it would materially and adversely affect EVgo’s business, operating results, financial condition and prospects.

Rideshare and commercial fleets may not electrify as quickly as expected and may not rely on public fast charging or on EVgo’s network as much as expected. Future demand for or availability of battery EVs from the medium- and heavy-duty vehicle segment may not develop as anticipated or take longer to develop than expected.

The EV market is in the early stages of development and the medium- and heavy-duty vehicle segments, often particularly exposed to economic cycles, may not electrify as expected or on the timeline that is expected. The medium- and heavy-duty vehicle fleets that lend themselves well to electrification via EV powertrains are often linked to municipal and commercial budgets and may take longer to electrify as a result of budget or business constraints and administrative approvals. The mix of zero and low emission powertrains in certain vehicle classes and use cases in the medium- and heavy-duty sector may evolve less favorably for EV solutions due to future development of technologies and policy incentives that may favor existing diesel fuel, hybrid, natural gas or hydrogen fuel cell drivetrains. Medium- and heavy-duty vehicle OEMs may choose not to or may not be able to manufacture EVs in sufficient quantities or at all.

EVgo derives revenue from the sale of regulatory credits. There are a number of factors beyond EVgo’s control that could have a material adverse effect on EVgo’s ability to generate such revenue.

In connection with the production, delivery, placement into service and ongoing operation of charging stations, EVgo earns and expects to continue to earn various tradable regulatory credits, in particular California’s LCFS credits. EVgo currently participates in California’s LCFS program, Oregon’s Clean Fuels Program, and Washington’s Clean Fuel Standard program. EVgo sells these credits and expects to continue to sell future credits, to entities that generate deficits under the LCFS programs and are obligated to purchase the credits and use them to offset their deficits or emissions, primarily petroleum refiners and marketers and other entities that can use the credits to comply with the program requirements. However, there is no guarantee that such credits will continue to be available for sale at prices forecasted by the Company, or that regulatory restrictions would not be imposed on the proceeds from the sale of such credits in the future. See Part I, Item IA, “Risk Factors — Risks Related to the EV Market — The EV market currently benefits from the availability of rebates, tax credits and other financial incentives from governments, utilities and others to offset the purchase or operating cost of EVs and EV charging stations. The reduction, modification or elimination of such benefits could adversely affect EVgo’s financial results.” For example, LCFS credit pricing may fluctuate based on policies set by the California Air Resources Board (“CARB”). CARB is expected to hold a board vote in 2024 to modify the LCFS and related Fast Charging Infrastructure program. Further, EVgo may not be able to market all LCFS credits, may have to sell LCFS credits at below projected prices or may not be able to sell LCFS credits at all. EVgo’s inability to generate revenue from the sale of regulatory credits could have a materially adverse effect on EVgo’s future financial results.

The EV market currently benefits from the availability of rebates, tax credits and other financial incentives from governments, utilities and others to offset the purchase or operating cost of EVs and EV charging stations. The reduction, modification or elimination of such benefits could adversely affect EVgo’s financial results.

The U.S. federal government and some state and local governments provide incentives to end users and owners of EVs and EV charging stations in the form of rebates, tax credits, low-cost funding and other financial incentives, which could, in the future, be reduced or eliminated, including as a result of legislative or regulatory action introduced following presidential or congressional elections. The EV market relies on these governmental rebates, tax credits and other financial incentives to significantly lower the effective price of EVs and EV charging stations and to otherwise financially support these industries. However, these incentives may expire on a particular date, end when the allocated funding is exhausted, or may be reduced or terminated as a matter of regulatory or legislative policy. For example, the results of the 2024 Presidential and Congressional elections and resulting legislative or regulatory actions, if pursued, could impact the availability or value of these incentives or reduce access to such low-cost funding.

In particular, EVgo has historically claimed federal tax credits under Section 30C of the Code. The Inflation Reduction Act revised the credits under Section 30C of the Code to (i) retroactively extend the expiration of the credit as of December 31, 2021 (with such credit continuing to be capped at $30,000 per location for EV charging stations placed in service before January 1, 2023) until December 31, 2032, (ii) revised the credit structure, availability and requirements for EV charging stations placed in service after December 31, 2022 and (iii) introduced the concept of transferability of tax credits, providing an additional option to monetize such credits. As part of the revised credit structure and requirements for EV charging stations placed in service after December 31, 2022, the available Section 30C credit was expanded such that it is capped at $100,000 per item; however, in order to be eligible for such tax credit, EV charging stations must be installed in rural or low-income census tracts. Additionally, in order to receive the full tax credit, labor for EV charging station construction and maintenance must meet prevailing wage and apprenticeship requirements unless an exception applies. There can be no assurance that the EV charging stations placed in service by EVgo will meet the revised requirements for the Section 30C credits, and compliance with such requirements could increase EVgo’s labor and other costs. Any reduction in rebates, tax credits or other financial incentives available to EVs or EV charging stations, could negatively affect the EV market and adversely impact EVgo’s business operations and expansion potential. In addition, there is no assurance EVgo will have the necessary tax attributes to utilize any such credits that are available and may not be able to monetize such credits on favorable terms. Further, certain features of EVgo OpCo’s ownership may limit the available tax credit that can be monetized or utilized. See Part I, Item IA, “Risk Factors — Financial, Tax and Accounting-Related Risks — Changes to U.S. applicable U.S. tax laws and regulations or exposure to additional income tax liabilities could affect EVgo’s and EVgo OpCo’s business and future profitability.”

Federal guidance on Buy America requirements applicable to the NEVI Program, which was established by the Bipartisan Infrastructure Law, requires immediate domestic assembly and U.S. steel requirements for chargers to qualify for funding under the NEVI program, with higher domestic content percentages required in 2024. EVgo may be unable to source Buy America-compliant chargers in time to take advantage of early NEVI funding opportunities or only at increased costs. EVgo’s customers may request delays or adjustments to their build-out plans in order to accommodate these added Buy America requirements, which could result in delays in receipt of revenue from customers.

New tariffs and policies that could incentivize overbuilding of infrastructure may also have a negative impact on the economics of EVgo’s stations. Furthermore, new tariffs and policy incentives could be put in place that favor equipment manufactured by or assembled at American factories, which may put EVgo’s fast charging equipment vendors at a competitive disadvantage, including by increasing the cost or delaying the availability of charging equipment, by challenging or delaying EVgo’s ability to apply or qualify for grants and other government incentives, or for certain charging infrastructure build-out solicitations and programs, including those initiated by federal government agencies.

Moreover, a variety of incentives and rebates offered by the U.S. federal government as well as state and local governments in order to encourage the use of EVs may be limited or reduced. In particular, the U.S. federal government offers a tax credit, the maximum amount of which is $7,500, for qualified new plug-in EVs. The Inflation Reduction Act modified the tax credit for new plug-in EVs and added new tax credits for used and commercial EVs. The Inflation Reduction Act removed the phase-out of tax credits for new plug-in EVs with respect to vehicle manufacturers that reached certain production levels beginning in 2023. However, the tax credit is subject to additional requirements and limitations, such as certain adjusted gross income limits for consumers claiming the credit, domestic content requirements for critical

minerals and batteries and a requirement for final assembly to occur in North America. Such additional requirements and limitations for such tax credits may reduce incentives available to encourage the adoption of EVs; favor competitors whose production chains enable them to more readily take advantage of such incentives; delay purchases and installations of charging equipment by the Company as manufacturing of charging equipment is moved to the U.S. in order to expand eligibility for such incentives (which, in turn, could delay the Company’s recognition of revenue in connection with such stalls); increase the cost of procurement of some inputs in the construction of charging infrastructure; and negatively affect the EV market and adversely impact EVgo’s business operations and expansion potential. Any such developments could have an adverse effect on EVgo’s business, financial condition and results of operations.

Risks Related to EVgo’s Technology, Intellectual Property and Infrastructure

EVgo may need to defend against intellectual property infringement or misappropriation claims, which may be time-consuming and expensive and EVgo’s business could be adversely affected.

From time to time, the holders of intellectual property rights may assert their rights and urge the Company to take licenses and/or may bring suits alleging infringement or misappropriation of such rights. There can be no assurance that EVgo will be able to mitigate the risk of potential suits or legal demands by competitors or other third parties. Accordingly, EVgo may consider entering into licensing agreements with respect to such rights, although no assurance can be given that such licenses can be obtained on acceptable terms or at all, or that litigation or arbitration will not occur. Such licenses and associated disputes could significantly increase EVgo’s operating expenses. If EVgo is unable to successfully resolve any such dispute, EVgo may be required to cease making, selling or incorporating certain key components or intellectual property into the products and services EVgo offers, to pay substantial damages and/or royalties, to redesign EVgo’s products and services and/or to establish and maintain alternative branding. In addition, to the extent that EVgo’s customers and business partners become the subject of any allegation or claim regarding the infringement or misappropriation of intellectual property rights related to EVgo’s products and services, EVgo may be required to indemnify such customers and business partners. The scope of these indemnity obligations varies, but may, in some instances, include indemnification for damages and expenses, including attorneys’ fees. Even if EVgo is not a party to any litigation between a customer or business partner and a third party relating to infringement by EVgo’s products, an adverse outcome in any such litigation could make it more difficult for the Company to defend EVgo’s products against intellectual property infringement claims in any subsequent litigation in which EVgo is a named party. If EVgo is required to take one or more such actions, EVgo’s business, prospects, brand, operating results and financial condition could be materially and adversely affected. In addition, any litigation or claims, whether or not valid, could result in substantial costs, negative publicity, reputational harm and diversion of resources and management attention.

EVgo’s business may be adversely affected if EVgo is unable to maintain, protect and enforce its technology and intellectual property.

EVgo’s success depends, in part, on EVgo’s ability to protect EVgo’s core technology and intellectual property. To accomplish this, EVgo relies on and plans to continue relying on, a combination of trade secrets (including know-how), employee and third-party nondisclosure agreements, copyrights, trademarks, intellectual property licenses and other contractual rights to retain ownership of and protect, EVgo’s technology and intellectual property. Despite EVgo’s efforts to protect its intellectual property, third parties may attempt to copy or otherwise obtain and use EVgo’s intellectual property or seek court declarations that EVgo’s intellectual property is invalid or unenforceable, or that they do not infringe upon EVgo’s intellectual property. Monitoring unauthorized use of EVgo’s intellectual property is difficult and costly, and the steps EVgo has taken or may take in the future in an effort to prevent or combat infringement, misappropriation or other violations may be unsuccessful. Any litigation could result in significant expense to EVgo, including the diversion of management’s time, and may not ultimately be resolved in EVgo’s favor. As of December 31, 2023, EVgo held 23 patents and had 10 additional patent applications pending in the U.S. and abroad. Failure to adequately protect and enforce EVgo’s technology and intellectual property could result in competitors offering similar products, potentially resulting in the loss of some of EVgo’s competitive advantage and a decrease in revenue which would adversely affect EVgo’s business, prospects, financial condition and operating results.

The measures EVgo takes to protect EVgo’s technology and intellectual property from infringement, misappropriation or unauthorized use by others may not be effective for various reasons, including the following:

Intellectual property and trade secret laws vary significantly throughout the world. Some foreign countries do not protect intellectual property rights to the same extent as do the laws of the U.S. Further, policing the unauthorized use of EVgo’s intellectual property in foreign jurisdictions may be costly, difficult or even impossible. Therefore, EVgo’s intellectual property rights may not be as strong or as easily enforced outside of the U.S.

Any issued patent which may result from the pending patent application may come to be considered “standards essential.” If this is the case, EVgo may be required to license certain technology on “fair, reasonable and non-discriminatory” terms, which may decrease EVgo’s revenue. Further, competitors, vendors, or customers may, in certain instances, be free to create variations or derivative works of EVgo’s technology and intellectual property and those derivative works may become directly competitive with EVgo’s offerings. Finally, EVgo may not be able to leverage, or obtain ownership of, all technology and intellectual property developed by EVgo’s vendors in connection with design and manufacture of EVgo’s products, thereby jeopardizing EVgo’s ability to obtain a competitive advantage over EVgo’s competitors.

The current lack of industry standards may lead to uncertainty, additional competition and further unexpected costs.

The EV industry is new and evolving as are the standards governing EV charging which have not had the benefit of time-tested use cases. These immature industry standards could result in future incompatibilities and issues that could require significant resources and/or time to remedy. Utilities and other large market participants also mandate their own adoption of specifications that have not become widely adopted in the industry and may hinder innovation or slow new product or new feature introduction.

In addition, automobile manufacturers, such as Tesla, may choose to develop and promulgate their own proprietary charging standards and systems, which could lock out competition for EV charging stations, or to use their size and market position to influence the market, which could limit EVgo’s market and reach to customers, negatively impacting EVgo’s business.

Further, should regulatory bodies or large market participants later impose a standard that is not compatible with EVgo’s infrastructure or products, EVgo may incur significant costs to adapt EVgo’s business model to the new standard, which may require significant time and expense and, as a result, have a material adverse effect on EVgo’s revenues or results of operations.

For example, Tesla’s charging network in the United States is based on a proprietary connector and EV inlet, which Tesla has open sourced as the North American Charging Standard (“NACS”), to supplant or replace competing connector and EV inlet standards such as the combined charging system (“CCS”). In 2023 and 2024, a majority of the largest OEMs announced plans to adopt the NACS standard in their future EVs. SAE International, a standards-developing organization for automotive engineering professionals, is currently working on an initiative to adapt Tesla’s specifications for NACS into an industry standard.

The rapid industry shift towards the NACS standard demonstrates the ongoing evolution of industry standards. With the recent OEM announcements, NACS is poised to potentially become the de facto charging standard for EVs in North America. However, widespread or universal adoption of NACS as the industry standard could take several years as OEMs develop new EVs and EVSE manufacturers develop new chargers based on the NACS standard. Additionally, because a change in industry standard requires updates to a range of charging equipment, including EV inlets and EVSE connectors, cables and cooling systems, charging network operators, including EVgo, may have to spend considerable time and resources to deploy the new chargers (or retrofit existing chargers) in a manner that supports migration of EVs in North America from the CCS1 standard to the NACS standard while ensuring that existing EVs featuring CCS1 charging equipment are able to charge effectively on the updated networks.

Hardware or software utilized in connection with EVgo’s charging network could have undisclosed or undetected defects, errors or bugs which could impede market acceptance, harm EVgo’s standing among its current or prospective customers and/or potentially subject it to legal claims and liabilities, any of which could significantly impact EVgo’s business operations in an adverse manner.

EVgo may be subject to claims that persons were injured or purported to be injured, or that personal property has been damaged, including due to latent defects, in connection with the use of EVgo’s charging stations. Any insurance that EVgo carries may not be sufficient or it may not apply to all situations. Similarly, to the extent that such malfunctions are related to components obtained from third-party vendors, EVs produced by third-party OEMs (including any components of such EVs) or adaptors or other equipment obtained manufactured by other third parties, such third parties may not assume responsibility for such malfunctions. Any of these events could adversely affect EVgo’s brand, reputation, operating results or financial condition.

EVgo’s software platform is complex and includes a number of licensed third-party commercial and open-source software libraries. EVgo’s software may contain latent defects or errors that may be difficult to detect and remediate. EVgo is continuing to evolve the features and functionality of EVgo’s platform through updates and enhancements and as EVgo does so, EVgo may introduce additional defects or errors that may not be detected until after deployment to customers. In addition, if EVgo’s products and services, including any updates or patches, are not implemented or used correctly or as intended, inadequate performance and disruptions in service may result.

Any defects or errors in product or service offerings, or the perception of such defects or errors, or other performance problems could result in any of the following, each of which could adversely affect EVgo’s business and results of operations:

​

EVgo also faces the risk that any contractual protections EVgo seeks to include in EVgo’s agreements with customers are rejected, not implemented uniformly or do not fully or effectively protect from claims by customers, resellers, business partners or other third parties. In addition, any insurance coverage or indemnification obligations of suppliers or other third parties for EVgo’s benefit may not adequately cover all such claims or may cover only a portion of such claims. A successful product liability, systematic defect, warranty, or other similar claim could have an adverse effect on EVgo’s business, operating results and financial condition. In addition, even claims that ultimately are unsuccessful could result in expenditure of funds in litigation, divert management’s time and other resources and cause reputational harm.

The EV charging market is characterized by rapid technological change, which requires the Company to continue to develop new products, enhance their reliability and develop product innovations. Any delays in such development could adversely affect market adoption of EVgo’s products and financial results.

Continuing technological changes in battery and other EV technologies could adversely affect adoption of current EV charging technology, continuing and increasing reliance on EV charging infrastructure and/or the use of EVgo’s products and services. EVgo’s future success will depend in part upon EVgo’s ability to develop and introduce a variety of new capabilities and innovations to EVgo’s existing product offerings, as well as introduce a variety of new and improved product offerings to address the changing needs of the EV charging market.

As EV technologies change, EVgo may need to upgrade or adapt EVgo’s charging station technology and introduce new products and services in order to serve vehicles that have the latest technology, in particular major improvements in battery technology leading to significant increases in charging rates, which could involve substantial costs. Even if EVgo is able to keep pace with changes in technology and develop new products and services, EVgo’s research and development expenses could increase, EVgo’s gross margins could be adversely affected in some periods and EVgo’s prior products could become obsolete more quickly than expected.

EVgo cannot guarantee that any new products will be released in a timely manner, or at all, or achieve market acceptance. Delays in delivering new products that meet customer requirements could damage EVgo’s relationships with customers and lead them to seek alternative products or services. Delays in introducing products, improvements and innovations or the failure to offer innovative products or services at competitive prices may cause existing and potential customers to use EVgo’s competitors’ products or services.

If EVgo is unable to devote adequate resources to develop and improve products or cannot otherwise successfully develop products or services that meet customer requirements on a timely basis or that remain competitive with technological alternatives, EVgo’s products and services could lose market share, EVgo’s revenue will decline, EVgo may experience higher operating losses and EVgo’s business and prospects will be adversely affected.

EVgo expects to incur research and development costs and devote significant resources to developing new products, which could significantly reduce EVgo’s profitability and may never result in revenue to the Company.

EVgo’s future growth depends on penetrating new markets, adapting existing products to new applications and customer requirements and introducing new products that achieve market acceptance. EVgo plans to incur significant research and development costs in the future as part of EVgo’s efforts to design, develop, manufacture and introduce new products and enhance existing products. Further, EVgo’s research and development program may not produce successful results and EVgo’s new products may not achieve market acceptance, create additional revenue or become profitable.

EVgo may be unable to leverage customer data in all geographic locations, and this limitation may impact research and development operations.

EVgo relies on data collected through charging stations or EVgo’s mobile application. EVgo uses this data in connection with the research, development and analysis of EVgo’s technologies, creating and delivering value-add customer services and in assessing future charger locations as well as charging station capacities. EVgo’s inability to obtain necessary rights to use this data for the stations that EVgo does not own or freely transfer this data could result in delays or otherwise negatively impact EVgo’s research and development and expansion efforts and limit EVgo’s ability to derive revenues from value-add customer services. For instance, consumer privacy regulations may limit EVgo’s ability

to make fully informed, data driven business decisions, conduct microtargeting marketing strategies or provide microtargeting-based offerings to EV drivers.

Financial, Tax and Accounting-Related Risks

EVgo’s financial condition and results of operations are likely to fluctuate on a quarterly basis in future periods, which could cause EVgo’s results for a particular period to fall below expectations, resulting in a decline in the price of EVgo’s common stock.

EVgo’s financial condition and results of operations have fluctuated in the past and may continue to fluctuate in the future due to a variety of factors, many of which are beyond EVgo’s control.

In addition to the other risks described herein, the following factors could also cause EVgo’s financial condition and results of operations to fluctuate on a quarterly basis:

Revenue and other operating results may fall short of the expectations of investors and financial analysts, which could have an adverse effect on the price of the Company’s common stock. In addition, fluctuations in operating results and cash flow could, among other things, give rise to short-term liquidity issues. See Part I, Item IA, “Risk Factors — Risks Related to EVgo’s Business — EVgo may need to raise additional funds, and these funds may not be available when needed or may only be available on unfavorable terms, which could impact the Company’s ability to fund its operations, its growth and the build-out of the Company’s network.”

EVgo has identified a material weakness in its internal control over financial reporting, and any inability to timely remediate this material weakness or to otherwise establish and maintain an effective system of internal control over financial reporting may harm investor confidence and cause a decline in the price of the Company’s Class A common stock.

In connection with the preparation of EVgo’s audited consolidated financial statements as of and for the year ended December 31, 2023, a material weakness was identified in EVgo’s internal control over financial reporting as discussed in more detail below. A material weakness is a deficiency, or a combination of deficiencies, in internal control over financial

reporting such that there is a reasonable possibility that a material misstatement of EVgo’s financial statements will not be prevented or detected on a timely basis. Notwithstanding such material weakness, EVgo’s management believes the consolidated financial statements included in this Annual Report present fairly, in all material respects, its financial position, results of operations and cash flows as of and for the periods presented, in accordance with U.S. GAAP.

The following material weakness in internal control over financial reporting was identified as of December 31, 2023: due to an ineffective information and communication process to ensure the completeness and accuracy of underlying data and reports, the Company did not effectively design, implement and operate process-level controls and effective general information technology (“IT”) controls relevant to its financial reporting processes. For further discussion of EVgo’s internal control over financial reporting and a description of the identified material weakness, see Part II, Item 9A, “Controls and Procedures” in this Annual Report.

As discussed further in that section, although EVgo is committed to remediating this material weakness and has implemented a remediation plan in order to address the identified material weakness, it may not be successful in making the improvements necessary to remediate it or to be able to do so in a timely manner. EVgo may also identify additional control deficiencies or material weaknesses in the future, or otherwise be unable to comply with the requirements of Section 404 the Sarbanes-Oxley Act of 2002, which may subject the Company to adverse regulatory consequences, negatively impact EVgo’s ability to produce timely and accurate financial statements in the future, harm investor confidence in the accuracy and completeness of its financial reporting, adversely affect its business and operating results and cause a decline in the price of the Company’s Class A common stock.

Changes to applicable U.S. tax laws and regulations or exposure to additional income tax liabilities could affect EVgo’s and EVgo OpCo’s business and future profitability.

EVgo has no material assets other than its indirect interest in EVgo OpCo, which holds, directly or indirectly, all of the operating assets of the EVgo business. EVgo OpCo generally will not be subject to U.S. federal income tax but may be subject to certain U.S. state and local and non-U.S. taxes. EVgo is a U.S. corporation that will be subject to U.S. corporate income tax on EVgo’s worldwide operations, including EVgo’s share of income of EVgo OpCo. Moreover, EVgo’s operations and customers are located in the U.S. As a result, EVgo and EVgo OpCo are subject to various U.S. federal, state and local taxes and EVgo’s future effective tax rates could be subject to volatility or adversely affected by a number of factors, including:

For example, the recently enacted Inflation Reduction Act extends and expands certain tax credits for EVs and EV charging infrastructure. As part of these changes, EV charging infrastructure and purchasers of EVs will be subject to additional requirements and/or limitations which may reduce the credits for which EVgo and EV consumers may be eligible and may affect the adoption of EVs and impact the demand for EV charging stations. In particular, certain prevailing wage and apprenticeship requirements may increase the cost to place in service EV charging stations, unless an exception applies. The exact impact of these changes is not fully known and may, in some circumstances, depend on guidance issued by the U.S. Department of the Treasury (“Treasury”) regarding the interpretation and implementation of the Inflation Reduction Act. Treasury has issued only limited guidance on the interpretation and implementation of the Inflation Reduction Act and additional guidance may be forthcoming. If and when issued, such guidance may impose further requirements and/or limitations. These and any other changes to government incentives that impose additional restrictions could increase costs, limit EVgo’s ability to utilize tax benefits, reduce its competitiveness and/or adversely impact EVgo’s growth, which could have a material adverse effect on EVgo’s business, financial condition and results of operations.

EVgo also may be subject to audits of EVgo’s or EVgo OpCo’s income, sales and other transaction taxes by U.S. federal, state and local taxing authorities. Outcomes of these audits could have an adverse effect on EVgo’s operating results and financial condition.

As a result of plans to expand EVgo’s business operations, including to jurisdictions in which tax laws may not be favorable, EVgo’s and EVgo OpCo’s obligations may change or fluctuate, become significantly more complex or become subject to greater risk of examination by taxing authorities, any of which could adversely affect EVgo’s or EVgo OpCo’s after-tax profitability and financial results.

In the event EVgo’s operating business expands domestically or internationally, EVgo’s and EVgo OpCo’s effective tax rates may fluctuate widely in the future. Future effective tax rates could be affected by operating losses in jurisdictions where no tax benefit can be recorded under GAAP, changes in deferred tax assets and liabilities, or changes in tax laws. Additionally, EVgo and EVgo OpCo may be subject to tax on more than 100% of EVgo’s income as a result of such income being subject to tax in multiple state, local or non-U.S. jurisdictions. Factors that could materially affect EVgo’s and EVgo OpCo’s future effective tax rates include but are not limited to: (a) changes in tax laws or the regulatory environment, (b) changes in accounting and tax standards or practices, (c) changes in the composition of operating income by tax jurisdiction and (d) pre-tax operating results of EVgo’s business.

Additionally, EVgo and EVgo OpCo may be subject to significant income, withholding and other tax obligations in the U.S. and may become subject to taxation in numerous additional state, local and non-U.S. jurisdictions with respect to income, operations and subsidiaries related to those jurisdictions. EVgo’s and EVgo OpCo’s after-tax profitability and financial results could be subject to volatility or be affected by numerous factors, including (a) the availability of tax deductions, credits, exemptions, refunds and other benefits to reduce tax liabilities, (b) changes in the valuation of deferred tax assets and liabilities, if any, (c) the expected timing and amount of the release of any tax valuation allowances, (d) the tax treatment of share-based compensation, (e) changes in the relative amount of earnings subject to tax in the various jurisdictions, (f) the potential business expansion into, or the Company otherwise becoming subject to tax in, additional jurisdictions, (g) changes to existing intercompany structure (and any costs related thereto) and business operations, (h) the extent of intercompany transactions and the extent to which taxing authorities in relevant jurisdictions respect those intercompany transactions and (i) the ability to structure business operations in an efficient and competitive manner. Outcomes from audits or examinations by taxing authorities could have an adverse effect on EVgo’s or EVgo OpCo’s after-tax profitability and financial condition. Additionally, the IRS and several foreign tax authorities have increasingly focused attention on intercompany transfer pricing with respect to sales of products and services and the use of intangibles. Tax authorities could disagree with EVgo’s or EVgo OpCo’s intercompany charges, cross-jurisdictional transfer pricing or other matters and assess additional taxes. If EVgo or EVgo OpCo, as applicable, do not prevail in any such disagreements, EVgo’s profitability may be adversely affected.

EVgo’s or EVgo OpCo’s after-tax profitability and financial results may also be adversely affected by changes in relevant tax laws and tax rates, treaties, regulations, administrative practices and principles, judicial decisions and interpretations thereof, in each case, possibly with retroactive effect.

Continuing or worsening inflationary pressures and associated changes in monetary policy may result in increases to the cost of EVgo’s charging equipment, other goods, services and personnel, which in turn could cause capital expenditures and operating costs to rise.

Recent inflationary pressures have resulted in and may continue to result in, increases to the costs of charging equipment and personnel, which could in turn cause capital expenditures and operating costs to rise. Sustained levels of high inflation have likewise caused the U.S. Federal Reserve and other central banks to increase interest rates, which could have the effects of raising the cost of capital and depressing economic growth, either of which—or the combination thereof—could hurt the financial and operating results of EVgo’s business.

Adverse developments affecting the financial services industry, such as actual events or concerns involving liquidity, defaults, or non-performance by financial institutions or transactional counterparties, could adversely affect the Company’s current and projected business operations and its financial condition and results of operations.

Events involving limited liquidity, defaults, non-performance, or other adverse developments that affect financial institutions, transactional counterparties or other companies in the financial services industry or the financial services industry generally, or concerns or rumors about any events of these kinds or other similar risks, have in the past and may in the future lead to market-wide liquidity problems. Even though the Company assesses its banking and customer relationships as it believes necessary or appropriate, the Company’s access to funding sources and other credit arrangements in amounts adequate to finance or capitalize its current and projected future business operations could be significantly impaired by factors that affect the Company, the financial services industry or the economy in general. These factors could include, among others, events such as liquidity constraints or failures, the ability to perform obligations under various types of financial, credit or liquidity agreements or arrangements, disruptions or instability in the financial services industry or financial markets, or concerns or negative expectations about the prospects for companies in the financial services industry.

The results of events or concerns that involve one or more of these factors could include a variety of material and adverse impacts on the Company’s current and projected business operations and financial condition and results of operations. These factors could include, but may not be limited to, the following:

In addition, investor concerns regarding the U.S. or international financial systems could result in less favorable commercial financing terms, including higher interest rates or costs and more restrictive financial and operating covenants, or systemic limitations on access to credit and liquidity sources, thereby making it more difficult for the Company to obtain financing on acceptable terms or at all. Any decline in available funding or access to the Company’s cash and liquidity resources could, among other risks, adversely impact the Company’s ability to meet its operating expenses, financial obligations or fulfill its other obligations, result in breaches of its contractual obligations or result in violations of federal or state wage and hour laws. Any of these impacts, or any other impacts resulting from the factors described above or other related or similar factors not described above, could have material adverse impacts on the Company’s liquidity and its business, financial condition or results of operations.

Risks Related to EVgo’s “Up-C” Structure and the Tax Receivable Agreement

EVgo Holdings owns the majority of EVgo’s voting stock and therefore has the right to appoint a majority of EVgo’s board members, and its interests may conflict with those of other stockholders.

EVgo Holdings owns the majority of EVgo’s voting stock and is therefore entitled to appoint the majority of the Board of Directors. As a result, EVgo Holdings is able to substantially influence matters requiring EVgo’s stockholder or board approval, including the election of directors, approval of any of EVgo’s potential acquisitions, changes to EVgo’s organizational documents and significant corporate transactions. This concentration of ownership makes it unlikely that any other holder or group of holders of Class A common stock will be able to affect the way EVgo is managed or the direction of EVgo’s business. The interests of EVgo Holdings with respect to matters potentially or actually involving or affecting the Company, such as future acquisitions, financings and other corporate opportunities and attempts to acquire the Company, may conflict with the interests of EVgo’s other stockholders.

For example, EVgo Holdings may have different tax positions from the Company, especially in light of the Tax Receivable Agreement that could influence its decisions regarding whether and when to support the disposition of assets

or the incurrence or refinancing of new or existing indebtedness, or the termination of the Tax Receivable Agreement and acceleration of EVgo’s obligations thereunder. In addition, the determination of future tax reporting positions, the structuring of future transactions and the handling of any challenge by any taxing authority to EVgo’s tax reporting positions may take into consideration tax or other considerations of EVgo Holdings, including the effect of such positions on EVgo’s obligations under the Tax Receivable Agreement, which may differ from EVgo’s considerations or the considerations of other stockholders. For additional information, see Part II, Item 8, “Consolidated Financial Statements and Supplementary Data — Note 16 — Tax Receivable Agreement.”

EVgo’s only principal asset is EVgo’s interest in Thunder Sub, which, in turn, holds only units issued by EVgo OpCo; accordingly, EVgo depends on distributions from EVgo OpCo and Thunder Sub to pay taxes, make payments under the Tax Receivable Agreement and cover EVgo’s corporate and other overhead expenses.

EVgo is a holding company and has no material assets other than EVgo’s ownership interest in Thunder Sub. Thunder Sub holds only EVgo OpCo Units, which at the time immediately following the CRIS Close Date were equal to the number of shares of Class A common stock issued and outstanding after giving effect to the CRIS Business Combination and the PIPE. Neither EVgo nor Thunder Sub has independent means of generating revenue or cash flow. To the extent EVgo OpCo has available cash and subject to the terms of any current or future debt instruments, the EVgo OpCo A&R LLC Agreement requires EVgo OpCo to make pro rata cash distributions to holders of EVgo OpCo Units, including Thunder Sub, in an amount sufficient to allow the Company Group to pay its taxes and to make payments under the Tax Receivable Agreement. EVgo generally expects EVgo OpCo to fund such distributions out of available cash and if payments under the Tax Receivable Agreement are accelerated, EVgo generally expects to fund such accelerated payments out of the proceeds of the change of control transaction giving rise to such acceleration. When EVgo OpCo makes distributions, the holders of EVgo OpCo Units will be entitled to receive proportionate distributions based on their interests in EVgo OpCo at the time of such distribution. In addition, the EVgo OpCo A&R LLC Agreement requires EVgo OpCo to make non-pro rata payments to Thunder Sub to reimburse it for its corporate and other overhead expenses, which payments are not treated as distributions under the EVgo OpCo A&R LLC Agreement. To the extent that EVgo needs funds and EVgo OpCo or its subsidiaries are restricted from making such distributions or payments under applicable law or regulation or under the terms of any current or future financing arrangements, or are otherwise unable to provide such funds, EVgo’s liquidity and financial condition could be materially adversely affected.

Moreover, because EVgo has no independent means of generating revenue, EVgo’s ability to make tax payments and payments under the Tax Receivable Agreement is dependent on the ability of EVgo OpCo to make distributions to Thunder Sub in an amount sufficient to cover the Company Group’s tax obligations and obligations under the Tax Receivable Agreement. This ability, in turn, may depend on the ability of EVgo OpCo’s subsidiaries to make distributions to it. The ability of EVgo OpCo, its subsidiaries and other entities in which it directly or indirectly holds an equity interest to make such distributions will be subject to, among other things, (i) the applicable provisions of Delaware law (or other applicable jurisdiction) that may limit the amount of funds available for distribution and (ii) restrictions in relevant debt instruments issued by EVgo OpCo or its subsidiaries and other entities in which it directly or indirectly holds an equity interest. To the extent that EVgo is unable to make payments under the Tax Receivable Agreement for any reason, such payments will be deferred and will accrue interest until paid.

EVgo will be required to make payments under the Tax Receivable Agreement for certain tax benefits that EVgo may claim, and the amounts of such payments could be significant.

In connection with the CRIS Business Combination, EVgo entered into the Tax Receivable Agreement. This agreement generally provides for the payment by the Company Group to EVgo Holdings of 85% of the net cash savings, if any, in U.S. federal, state and local income tax and franchise tax (computed using simplifying assumptions to address the impact of state and local taxes) that the Company Group actually realizes (or is deemed to realize in certain circumstances) in periods after the consummation of the CRIS Business Combination as a result of certain increases in tax basis available to the Company Group as a result of the CRIS Business Combination, the acquisition of EVgo OpCo Units pursuant to an exercise of the EVgo OpCo Unit Redemption Right (as defined in the EVgo OpCo A&R LLC Agreement) or the Call Right (as defined in the EVgo OpCo A&R LLC Agreement) (including any increases in tax basis relating to prior transfers of such EVgo OpCo Units that will be available to the Company Group as a result of its acquisition of such EVgo OpCo Units) and certain benefits attributable to imputed interest. The Company Group will retain the benefit of the remaining net cash savings, if any.

The term of the Tax Receivable Agreement commenced upon the consummation of the CRIS Business Combination and will continue until all tax benefits that are subject to the Tax Receivable Agreement have been utilized or expired and all required payments are made, unless the Company Group exercises its right to terminate the Tax Receivable Agreement (or the Tax Receivable Agreement is terminated due to other circumstances, including the Company Group’s breach of a material obligation thereunder or certain mergers or other changes of control) and the Company Group makes the termination payment specified in the Tax Receivable Agreement. In addition, payments the Company Group makes under the Tax Receivable Agreement will be increased by any interest accrued from the due date (without extensions) of the corresponding tax return. During the year ended December 31, 2023, no transactions occurred that resulted in a cash tax savings benefit that would have triggered the recording of a liability by the Company based on the terms of the Tax Receivable Agreement.

The payment obligations under the Tax Receivable Agreement are the Company Group’s obligations and not obligations of EVgo OpCo and EVgo expects that the payments the Company Group will be required to make under the Tax Receivable Agreement will be substantial. Estimating the amount and timing of the Company Group’s realization of tax benefits subject to the Tax Receivable Agreement is by its nature imprecise. The actual increases in tax basis covered by the Tax Receivable Agreement, as well as the amount and timing of the Company Group’s ability to use any deductions (or decreases in gain or increases in loss) arising from such increases in tax basis, are dependent upon future events, including but not limited to the timing of redemptions of EVgo OpCo Units, the price of the Company’s Class A common stock at the time of each redemption, the extent to which such redemptions are taxable transactions, the amount of the redeeming member’s tax basis in its EVgo OpCo Units at the time of the relevant redemption, the depreciation and amortization periods that apply to the increase in tax basis, the amount, character and timing of taxable income the Company Group generates in the future, the timing and amount of any earlier payments that the Company Group may have made under the Tax Receivable Agreement, the U.S. federal income tax rate then applicable and the portion of the Company Group’s payments under the Tax Receivable Agreement that constitute imputed interest or give rise to depreciable or amortizable tax basis. Accordingly, estimating the amount and timing of payments that may become due under the Tax Receivable Agreement is also by its nature imprecise. For purposes of the Tax Receivable Agreement, net cash savings in tax generally are calculated by comparing the Company Group’s actual tax liability (determined by using the actual applicable U.S. federal income tax rate and an assumed combined state and local income tax rate) to the amount the Company Group would have been required to pay had it not been able to utilize any of the tax benefits subject to the Tax Receivable Agreement. Thus, the amount and timing of any payments under the Tax Receivable Agreement are also dependent upon significant future events, including those noted above in respect of estimating the amount and timing of the Company Group’s realization of tax benefits. Any distributions made by EVgo OpCo to the Company Group to enable the Company Group to make payments under the Tax Receivable Agreement, as well as any corresponding pro rata distributions made to the other holders of EVgo OpCo Units, could have an adverse impact on EVgo’s liquidity.

Payments under the Tax Receivable Agreement will not be conditioned upon a holder of rights under the Tax Receivable Agreement having an ownership interest in the Company or EVgo OpCo. In addition, certain rights of the holders of EVgo OpCo Units (including the right to receive payments) under the Tax Receivable Agreement will be transferable in connection with transfers permitted under the EVgo OpCo A&R LLC Agreement of the corresponding EVgo OpCo Units or after the corresponding EVgo OpCo Units have been acquired pursuant to the EVgo OpCo Unit Redemption Right or Call Right. For additional information, see Part II, Item 8, “Consolidated Financial Statements and Supplementary Data — Note 16 — Tax Receivable Agreement.”

In certain cases, payments under the Tax Receivable Agreement may be accelerated and/or significantly exceed the actual benefits, if any, the Company Group realizes in respect of the tax attributes subject to the Tax Receivable Agreement.

If EVgo experiences a change of control (as defined under the Tax Receivable Agreement, which includes certain mergers, asset sales and other forms of business combinations) or the Tax Receivable Agreement terminates early (at the Company Group’s election or as a result of the Company Group’s breach), the Company Group would be required to make an immediate payment equal to the present value of the anticipated future payments to be made by it under the Tax Receivable Agreement (determined by applying a discount rate equal to one-year LIBOR (or an agreed successor rate, if applicable) plus 100 basis points), and such early termination payment is expected to be substantial. The calculation of anticipated future payments will be based upon certain assumptions and deemed events set forth in the Tax Receivable Agreement, including (i) that the Company Group has sufficient taxable income on a current basis to fully utilize the tax

benefits covered by the Tax Receivable Agreement and (ii) that any EVgo OpCo Units (other than those held by the Company Group or its subsidiaries, other than EVgo OpCo) outstanding on the termination date or change of control date, as applicable, are deemed to be redeemed on such date. Any early termination payment may be made significantly in advance of and may materially exceed, the actual realization, if any, of the future tax benefits to which the early termination payment relates.

If EVgo experiences a change of control (as defined under the Tax Receivable Agreement) or the Tax Receivable Agreement otherwise terminates early (at the Company Group’s election or as a result of the Company Group’s breach), the Company Group’s obligations under the Tax Receivable Agreement could have a substantial negative impact on EVgo’s liquidity and could have the effect of delaying, deferring or preventing certain mergers, asset sales, or other forms of business combinations or changes of control. If the Company Group’s obligation to make payments under the Tax Receivable Agreement is accelerated as a result of a change of control, EVgo generally expects the accelerated payments due under the Tax Receivable Agreement to be funded out of the proceeds of the change of control transaction giving rise to such acceleration. However, the Company Group may be required to fund such payment from other sources and as a result, any early termination of the Tax Receivable Agreement could have a substantial negative impact on EVgo’s liquidity. EVgo does not currently expect to cause an acceleration due to the Company Group’s breach and EVgo does not currently expect that the Company Group would elect to terminate the Tax Receivable Agreement early, except in cases where the early termination payment would not be material. There can be no assurance that the Company Group will be able to meet its obligations under the Tax Receivable Agreement. For additional information, see “Part II, Item 8. Consolidated Financial Statements and Supplementary Data — Note 16 — Tax Receivable Agreement.”

If the Company Group’s payment obligations under the Tax Receivable Agreement are accelerated upon certain mergers, other forms of business combinations or other changes of control, the consideration payable to holders of Class A common stock could be substantially reduced.

If EVgo experiences a change of control (as defined under the Tax Receivable Agreement, which includes certain mergers, asset sales and other forms of business combinations), then the Company Group’s obligations under the Tax Receivable Agreement would be based upon certain assumptions and deemed events set forth in the Tax Receivable Agreement and in such situations, payments under the Tax Receivable Agreement may be significantly in advance of and may materially exceed, the actual realization, if any, of the future tax benefits to which the payment relates. As a result of the Company Group’s payment obligations under the Tax Receivable Agreement, holders of Class A common stock could receive substantially less consideration in connection with a change of control transaction than they would receive in the absence of such obligation. Further, the Company Group’s payment obligations under the Tax Receivable Agreement will not be conditioned upon holders of EVgo OpCo Units having a continued interest in the Company or EVgo OpCo. Accordingly, the interests of the holders of EVgo OpCo Units may conflict with those of the holders of Class A common stock. See Part I, Item IA, “Risk Factors — In certain cases, payments under the Tax Receivable Agreement may be accelerated and/or significantly exceed the actual benefits, if any, the Company Group realizes in respect of the tax attributes subject to the Tax Receivable Agreement.”

EVgo will not be reimbursed for any payments made under the Tax Receivable Agreement in the event that any tax benefits are subsequently disallowed.

Payments under the Tax Receivable Agreement will be based on the tax reporting positions that the Company Group will determine and the IRS or another tax authority may challenge all or part of the tax basis increases upon which payments under the Tax Receivable Agreement are based, as well as other related tax positions the Company Group takes and a court could sustain such challenge. The holders of EVgo OpCo Units will not reimburse the Company for any payments previously made under the Tax Receivable Agreement if any tax benefits that have given rise to payments under the Tax Receivable Agreement are subsequently disallowed, except that excess payments made to any holder of EVgo OpCo Units will be netted against future payments that would otherwise be made to such holder of EVgo OpCo Units, if any, after the Company Group’s determination of such excess (which determination may be made a number of years following the initial payment and after future payments have been made). As a result, in such circumstances, the Company Group could make payments that are greater than its actual cash tax savings, if any and may not be able to recoup those payments, which could materially adversely affect its liquidity.

If EVgo OpCo were to become a publicly traded partnership taxable as a corporation for U.S. federal income tax purposes, the Company and EVgo OpCo might be subject to potentially significant tax inefficiencies and EVgo would not be able to recover payments previously made by it under the Tax Receivable Agreement even if the corresponding tax benefits were subsequently determined to have been unavailable due to such status.

EVgo intends to operate such that EVgo OpCo does not become a publicly traded partnership taxable as a corporation for U.S. federal income tax purposes. A “publicly traded partnership” is a partnership the interests of which are traded on an established securities market or are readily tradable on a secondary market or the substantial equivalent thereof. Under certain circumstances, redemptions of EVgo OpCo Units pursuant to the EVgo OpCo Unit Redemption Right (or the Call Right) or other transfers of EVgo OpCo Units could cause EVgo OpCo to be treated as a publicly traded partnership. Applicable Treasury regulations provide for certain safe harbors from treatment as a publicly traded partnership and EVgo intends to operate such that redemptions or other transfers of EVgo OpCo Units qualify for one or more such safe harbors. For example, EVgo intends to limit the number of holders of EVgo OpCo Units and the EVgo OpCo A&R LLC Agreement, which was entered into in connection with the consummation of the CRIS Business Combination, provides for limitations on the ability of holders of EVgo OpCo Units to transfer their EVgo OpCo Units and provides Thunder Sub, as the managing member of EVgo OpCo, with the right to impose restrictions (in addition to those already in place) on the ability of holders of EVgo OpCo Units to redeem their EVgo OpCo Units pursuant to the EVgo OpCo Unit Redemption Right (or Call Right) to the extent EVgo believes it is necessary to ensure that EVgo OpCo will continue to be treated as a partnership for U.S. federal income tax purposes.

If EVgo OpCo were to become a publicly traded partnership taxable as a corporation for U.S. federal income tax purposes, significant tax inefficiencies might result for the Company and EVgo OpCo, including as a result of the Company Group’s inability to file a consolidated U.S. federal income tax return with EVgo OpCo. In addition, the Company Group may not be able to realize tax benefits covered under the Tax Receivable Agreement and the Company Group would not be able to recover any payments previously made by it under the Tax Receivable Agreement, even if the corresponding tax benefits (including any claimed increase in the tax basis of EVgo OpCo’s assets) were subsequently determined to have been unavailable.

Risks Related to Legal Matters and Regulations

Privacy concerns and laws, or other regulations, may adversely affect EVgo’s business.

State and local governments and agencies in the jurisdictions in which EVgo operates and in which customers operate, have adopted, are considering adopting, or may adopt laws and regulations regarding the collection, use, storage, processing and disclosure of information regarding consumers and other individuals, which could impact EVgo’s ability to offer services in certain jurisdictions. Laws and regulations relating to the collection, use, disclosure, security and other processing of individuals’ information can vary significantly from jurisdiction to jurisdiction. The costs of compliance with and other burdens imposed by laws, regulations, standards and other obligations relating to privacy, data protection and information security are significant. In addition, some companies, particularly larger enterprises, often will not contract with vendors that do not meet these rigorous standards. Accordingly, the failure, or perceived inability, to comply with these laws, regulations, standards and other obligations may limit the use and adoption of EVgo’s products and services, reduce overall demand, lead to regulatory investigations, litigation and significant fines, penalties, or liabilities for actual or alleged noncompliance, or slow the pace at which EVgo closes sales transactions, any of which could harm EVgo’s business. Moreover, if EVgo or any of EVgo’s employees or contractors fail or are believed to fail to adhere to appropriate practices regarding customers’ data, it may damage EVgo’s reputation and brand.

Additionally, existing laws, regulations, standards and other obligations may be interpreted in new and differing manners in the future and may be inconsistent among jurisdictions. Future laws, regulations, standards and other obligations and changes in the interpretation of existing laws, regulations, standards and other obligations could result in increased regulation, increased costs of compliance and penalties for non-compliance and limitations on data collection, use, disclosure and transfer for the Company and EVgo’s customers. Further, a number of states have comprehensive privacy laws applicable to EVgo and its data processing activities. For example, California adopted the California Consumer Privacy Protection Act (as amended by the California Private Rights Act, the “CCPA”), and California regulators have begun enforcement actions and issued regulations in connection with the CCPA. Although EVgo has developed a compliance program designed to ensure comply with these state privacy laws, EVgo remains exposed to risks

associated with the continued expansion and evolution of such laws. The costs of compliance with and other burdens imposed by laws and regulations relating to privacy, data protection and information security may adversely affect EVgo’s ability and willingness to process, handle, store, use and transmit certain types of information, such as demographic and other personal information.

In addition to government activity, privacy advocacy groups, the technology industry and other industries have established or may establish various new, additional or different self-regulatory standards that may place additional burdens on technology companies. Customers may expect that EVgo will meet voluntary certifications or adhere to other standards established by them or third parties. Any failure by or inability of EVgo to maintain these certifications or meet these standards could reduce demand for EVgo’s solutions and adversely affect EVgo’s business.

Existing and future environmental, accessibility, health and safety laws and regulations could result in increased compliance costs or additional operating costs or construction costs and restrictions. Failure to comply with such laws and regulations may result in substantial fines or other limitations that may adversely impact EVgo’s financial results or results of operation.

EVgo and EVgo’s operations, as well as those of EVgo’s contractors, suppliers and customers, are subject to certain environmental laws and regulations, including laws related to the use, handling, storage, transportation and disposal of hazardous substances and wastes, as well as electronic wastes and hardware, whether hazardous or not. These laws may require the Company or others in EVgo’s value chain to obtain permits and comply with procedures that impose various restrictions and obligations that may have material effects on EVgo’s operations. If key permits and approvals cannot be obtained on acceptable terms, or if other operational requirements cannot be met in a manner satisfactory for EVgo’s operations or on a timeline that meets EVgo’s commercial obligations, it may adversely impact EVgo’s business.

Environmental, accessibility, and health and safety laws and regulations can be complex and may be subject to change, such as through new requirements enacted at the supranational, national, sub-national and/or local level or new or modified regulations that may be implemented under existing law. The nature and extent of any changes in these laws, rules, regulations and permits may be unpredictable and may have material effects on EVgo’s business. Future legislation and regulations or changes in existing legislation and regulations, or interpretations thereof, including those relating to site design, hardware manufacturing, electronic waste, or batteries, could cause additional expenditures, restrictions and delays in connection with EVgo’s operations as well as other future projects, the extent of which cannot be predicted. For instance, more stringent laws or regulations for DC fast charging or companies that provide DC fast charging services may be enacted in the near future. EVgo’s charging stations have been constructed at various stages of development of the regulatory regime regarding accessibility. EVgo’s charging stations that have been constructed before regulations are issued may not comply with new regulations, which could subject the Company to penalties and enforcement actions. Additionally, EVgo could be regulated as a retail electric service provider in the future.

Further, EVgo currently relies on third parties to ensure compliance with certain environmental laws, including those related to the disposal of hazardous and non-hazardous wastes. Any failure to properly handle or dispose of wastes, regardless of whether such failure is the responsibility of EVgo or EVgo’s contractors, may result in liability under environmental laws, including, but not limited to, CERCLA and state analogs, under which liability may be imposed without regard to fault or degree of contribution for the investigation and clean-up of contaminated sites, as well as impacts to human health and damages to natural resources. EVgo may also generate or dispose of solid wastes, which may include hazardous wastes that are subject to the requirements of RCRA and comparable state statutes. While RCRA regulates both solid and hazardous wastes, it imposes strict requirements on the generation, storage, treatment, transportation and disposal of hazardous wastes. Certain components of EVgo’s charging stations may be excluded from RCRA’s hazardous waste regulations, provided certain requirements are met. However, if these components do not meet all of the established requirements for the exclusion, or if the requirements for the exclusion change, EVgo may be required to treat such products as hazardous waste, which are subject to more rigorous and costly disposal requirements. Any such changes in the laws and regulations, or EVgo’s ability to qualify the materials EVgo uses for exclusions under such laws and regulations, could adversely affect EVgo’s operating expenses. Additionally, EVgo may not be able to secure contracts with third parties to continue their key supply chain and disposal services for EVgo’s business, which may result in increased costs for compliance with environmental laws and regulations.

Separately, EVgo may also be subject to various supply chain requirements regarding, among other things, conflict minerals and labor practices. EVgo may be required to incur substantial costs to comply with these requirements and the failure to comply may result in substantial fines or other penalties that may adversely impact EVgo’s business, financial condition or results of operations.

Increasing attention to ESG matters may increase EVgo’s costs of compliance and adversely impact EVgo’s business.

There is an increased focus, including by governmental and nongovernmental organizations, investors, customers and other stakeholders on climate change matters, including increased pressure to expand disclosures related to the physical and transition risks related to climate change and to establish sustainability goals, such as the reduction of greenhouse gas emissions, which could expose EVgo to market, operational and execution costs or risks. EVgo’s failure to establish targets or targets that are perceived to be appropriate, as well as to achieve progress on those targets on a timely basis, or at all, could adversely affect the reputation of its brand and sales of and demand for its products. To the extent legislation is passed or regulations are adopted, EVgo could incur significant additional costs of compliance due to the need for expanded data collection, analysis and certification with respect to greenhouse gas emissions and other climate change related risks. For example, in March 2022, the SEC proposed new rules requiring public companies to disclose information related to their direct greenhouse gas emissions and indirect emissions from purchased energy, as well as specific categories of greenhouse gas emissions from upstream and downstream activities in the companies’ value chains, otherwise known as Scope 3 emissions. In addition, in 2023, several laws were adopted in California that impose climate-related disclosure obligations on companies, with the scope of the obligations depending in some respects on companies’ annual revenues.

If the SEC’s proposed emissions reporting rule is finalized, it could significantly increase EVgo’s compliance costs. EVgo may also incur additional costs or require additional resources to monitor, report and comply with stakeholder expectations and standards and legislation and to meet climate change targets and commitments if established. In particular, EVgo markets the electricity provided from EVgo’s charging stations as 100% matched with purchases of RECs. Certain ESG-focused investors and other stakeholders may instead favor direct purchases of renewable electricity, which in turn could lead the Company to choose to purchase electricity through such other sources, which could increase EVgo’s costs and have an adverse impact on EVgo’s results of operations.

Additionally, EVgo may receive requests for sustainability related information about its products, business operations and use of sustainable materials, among other data and may be required to satisfy certain ESG-related requirements as a condition to working with certain counterparties or participating in certain grant programs. Efforts to satisfy such requirements may result in increased costs and EVgo’s inability to comply with these and other sustainability requirements in the future could adversely affect sales of and demand for its products and its ability to participate in certain grant programs.

In addition, organizations that provide information to investors on corporate governance and related matters have developed ratings processes for evaluating companies on their approach to ESG matters. Unfavorable ESG ratings could lead to increased negative investor sentiment toward EVgo and could impact EVgo’s access to and costs of capital. Additionally, to the extent ESG matters negatively impact EVgo’s reputation, EVgo may not be able to compete as effectively to recruit or retain employees, which may adversely affect EVgo’s business. Such ESG matters may also impact EVgo’s suppliers, which may adversely impact EVgo’s business and financial condition.

Risks Related to EVgo’s Securities

EVgo is a “controlled company” within the meaning of the rules of the Nasdaq and the rules of the SEC. As a result, EVgo qualifies for and relies on, exemptions from certain corporate governance requirements that would otherwise provide protection to stockholders of other companies.

Immediately following the completion of the CRIS Business Combination, EVgo Holdings controlled a majority of the voting power of EVgo’s outstanding common stock. As a result, EVgo is a “controlled company” within the meaning of the corporate governance standards of the Nasdaq. Under these rules, a company of which more than 50% of the voting

power is held by an individual, group or another company is a “controlled company” and may elect not to comply with certain corporate governance requirements, including:

Following the CRIS Business Combination, EVgo utilized some or all of these exemptions. As a result, EVgo’s nominating and corporate governance committee and compensation committee may not consist entirely of independent directors. Accordingly, you may not have the same protections afforded to stockholders of companies that are subject to all of Nasdaq’s corporate governance requirements.

Provisions in EVgo’s Charter and Delaware law may have the effect of discouraging lawsuits against EVgo’s directors and officers.

EVgo’s Charter requires, unless EVgo consents in writing to the selection of an alternative forum, that (a) the federal courts of the U.S. shall have exclusive jurisdiction to hear, settle and/or determine any dispute, controversy or claim arising under the federal securities laws; and (b) the Court of Chancery of the State of Delaware (the “Court of Chancery”) shall have exclusive jurisdiction to hear (i) any derivative action or proceeding brought on its behalf, (ii) any action asserting a claim of breach of a fiduciary duty owed by any director, officer or other employee to the Company or EVgo’s stockholders, (iii) any action asserting a claim against the Company, EVgo’s directors, officers or employees arising pursuant to any provision of the Delaware General Corporation Law or EVgo’s Charter or EVgo’s bylaws, or (iv) any action asserting a claim against the Company, EVgo’s directors, officers or employees governed by the internal affairs doctrine, in each case subject to such Court of Chancery having personal jurisdiction over the indispensable parties named as defendants therein. If an action described in clause (b) above is brought outside of Delaware, the stockholder bringing the suit will be deemed to have consented to service of process on such stockholder’s counsel. However, Section 22 of the Securities Act provides for concurrent federal and state court jurisdiction over actions under the Securities Act and the rules and regulations thereunder and there is uncertainty as to whether a court would enforce this provision as it relates to actions arising under the Securities Act.

Although EVgo believes this provision benefits the Company by providing increased consistency in the application of Delaware law in the types of lawsuits to which it applies, the provision may have the effect of discouraging lawsuits against EVgo’s directors and officers by limiting a stockholder’s ability to bring a claim against any of the Company’s directors, officers or stockholders in a judicial forum that it finds favorable, although EVgo’s stockholders will not be deemed to have waived EVgo’s compliance with federal securities laws and the rules and regulations thereunder.

Alternatively, if a court were to find the choice of forum provision in EVgo’s Charter to be inapplicable or unenforceable in an action, the Company may incur additional costs associated with resolving such action in other jurisdictions, which could harm the Company’s business, operating results and financial condition.

Provisions in EVgo’s Charter may inhibit a takeover of the Company, which could limit the price investors might be willing to pay in the future for Class A common stock and could entrench management.

EVgo’s Charter authorizes the Board of Directors to issue one or more classes or series of preferred stock, the terms of which may be established and the shares of which may be issued without stockholder approval and which may include super voting, special approval, dividend, repurchase rights, liquidation preferences or other rights or preferences superior to the rights of the holders of Class A common stock. The terms of one or more classes or series of preferred stock could adversely impact the value of the Class A common stock. Furthermore, if the Board of Directors elects to issue preferred stock, it could be more difficult for a third party to acquire the Company. For example, the Board of Directors may grant

holders of preferred stock the right to elect some number of directors in all events or upon the occurrence of specified events or the right to veto specified transactions.

In addition, some provisions of EVgo’s Charter could make it more difficult for a third party to acquire control of the Company, even if the change of control would be beneficial to the stockholders, including: (i) prohibiting the Company from engaging in any business combination with any interested stockholder for a period of three years following the time that the stockholder became an interested stockholder, subject to certain exceptions, (ii) establishing that provisions with regard to the nomination of candidates for election as directors are subject to the A&R Nomination Agreement, (iii) providing that the authorized number of directors may be changed only by resolution of the Board of Directors and in any case is subject to the A&R Nomination Agreement, (iv) providing that all vacancies in the Board of Directors may, except as otherwise be required, be filled by the affirmative vote of a majority of directors then in office, even if less than a quorum, (v) providing that EVgo’s Charter and bylaws may be amended and directors may be removed, by the affirmative vote of the holders of at least 75% of the then outstanding voting stock after LS Power owns less than 30% of EVgo’s voting capital stock, (vi) providing for the Board of Directors to be divided into three classes of directors, (vii) providing that the amended and restated bylaws can be amended by the Board of Directors, (viii) limitations on the ability of stockholders to call special meetings, (ix) limitations on the ability of stockholders to act by written consent and (x) renouncing any reasonable expectancy interest that EVgo has in, or right to be offered an opportunity to participate in, any corporate or business opportunities that are from time to time presented to LS Power, directors affiliated with LS Power, their respective affiliates and non-employee directors.

In addition, certain change of control events have the effect of accelerating the payments due under the Tax Receivable Agreement, which could result in a substantial, immediate lump-sum payment that could serve as a disincentive to a potential acquirer of the Company, please see “Financial, Tax and Accounting-Related Risks — In certain cases, payments under the Tax Receivable Agreement may be accelerated and/or significantly exceed the actual benefits, if any, the Company Group realizes in respect of the tax attributes subject to the Tax Receivable Agreement.”

LS Power, non-employee directors and their affiliates are not limited in their ability to compete with EVgo, and the corporate opportunity provisions in EVgo’s Charter could enable such persons to benefit from corporate opportunities that might otherwise be available to the Company.

EVgo’s Charter provides that (i) LS Power and any investment funds or entities controlled or advised by LS Power and (ii) non-employee directors and their affiliates (each, an “Identified Person”) would not be restricted from owning assets or engaging in businesses that compete directly or indirectly with the Company. In particular, subject to the limitations of applicable law and EVgo’s Charter, an Identified Person may, among other things:

One or more of the Identified Persons may become aware, from time to time, of certain business opportunities (such as acquisition opportunities) and may direct such opportunities to other businesses in which they have invested, in which case EVgo may not become aware of or otherwise have the ability to pursue such opportunity. Further, such businesses may choose to compete with EVgo for these opportunities, possibly causing these opportunities to not be available to the Company or causing them to be more expensive for EVgo to pursue. As a result, EVgo’s renunciation of its interest and expectancy in any business opportunity that may be from time to time presented to an Identified Person could adversely impact EVgo’s business or prospects if attractive business opportunities are procured by such parties for their own benefit rather than for EVgo’s.

The market price of EVgo’s Class A common stock could be adversely affected by, and EVgo’s stockholders may experience dilution as a result of, sales of substantial amounts of Class A common stock in the public or private markets, including sales by the Company, EVgo Holdings or other large holders.

The sale of a substantial number of shares of EVgo common stock by the Company, EVgo Holdings or any other holder of a substantial number of shares of EVgo’s Class A common stock in the public markets could have a material adverse effect on the price of EVgo’s Class A common stock and dilute EVgo’s stockholders. For instance, EVgo may be required to undertake a public or private offering of Class A common stock in order to use the net proceeds from such offering to purchase an equal number of EVgo OpCo Units from EVgo Holdings or in order to further scale its business. Additionally, if EVgo raised more equity capital from the sale of common stock, institutional or other investors may negotiate terms, including with respect to pricing, more favorable than the current prices of EVgo’s Class A common stock. See Part I, Item IA, “Risk Factors — Risks Related to EVgo’s Business — EVgo may need to raise additional funds, and these funds may not be available when needed or may only be available on unfavorable terms, which could impact the Company’s ability to fund its operations, its growth and the build-out of the Company’s network.”

On August 10, 2022, EVgo filed a Registration Statement on Form S-3 (File No. 333-266753), which permits the sale by EVgo of up to $750 million in shares of Class A common stock and preferred stock, the issuance of Class A common stock underlying EVgo’s warrants and the resale of a significant number of shares of Class A common stock and warrants by certain securityholders identified in the prospectus accompanying the registration statement. In November 2022, EVgo entered into a Distribution Agreement with J.P. Morgan Securities LLC, Evercore Group L.L.C. and Goldman Sachs & Co. LLC as sales agents, pursuant to which the Company may sell up to $200 million of shares of Class A common stock in “at the market” transactions at prevailing market prices (the “ATM Program”). During the year ended December 31, 2023, the Company completed an underwritten public equity offering of 30,123,129 shares of Class A common stock and sold 889,340 shares of Class A common stock pursuant to the ATM Program, with aggregate gross proceeds of $5.8 million. As of December 31, 2023, the Company had sold a total of 2,478,280 shares of Class A common stock under the ATM Program.

EVgo cannot predict the size of future issuances or sales of EVgo’s Class A common stock or the effect, if any, that future issuances and sales of shares of EVgo’s Class A common stock could have on the market price of EVgo’s Class A common stock.

Because EVgo has no current plans to pay cash dividends on Class A common stock for the foreseeable future, you may not receive any return on investment unless you sell Class A common stock for a price greater than that which you paid for it.

EVgo may retain future earnings, if any, for future operations, expansion and debt repayment and has no current plans to pay any cash dividends for the foreseeable future. Any decision to declare and pay dividends as a public company in the future will be made at the discretion of the Board of Directors and will depend on, among other things, EVgo’s results of operations, financial condition, cash requirements, contractual restrictions and other factors that the Board of Directors may deem relevant. In addition, EVgo’s ability to pay dividends may be limited by covenants under any existing or future facilities for indebtedness entered into by EVgo or EVgo’s subsidiaries. As a result, you may not receive any return on an investment in Class A common stock unless you sell Class A common stock for a price greater than that which you paid for it.

EVgo’s Warrants are exercisable for EVgo’s Class A common stock, and the exercise of such Warrants would increase the number of shares eligible for future resale in the public market and result in dilution to EVgo’s stockholders.

As of December 31, 2023, there were approximately 18,097,105 warrants outstanding, consisting of 14,948,536 Public Warrants originally sold as part of the units issued in the Company’s Initial Public Offering and 3,148,569 Private Placement Warrants originally sold to the Sponsor in a private sale prior to the Initial Public Offering. Each of these warrants is exercisable for one share of EVgo’s Class A common stock, in accordance with the terms of the warrant agreement governing such warrants. Any shares of EVgo’s Class A common stock issued upon exercise of the warrants will result in dilution to the then existing holders of Class A common stock and increase the number of shares eligible for resale in the public market. Sales of substantial numbers of such shares in the public market could adversely affect the market price of EVgo’s Class A common stock and dilute EVgo’s stockholders.

The warrants are being accounted for as a warrant liability and are being recorded at fair value upon issuance with changes in fair value each period reported in earnings, which may have an adverse effect on the market price of the Class A common stock.

As described in EVgo’s consolidated financial statements included in this Annual Report, EVgo is accounting for the Company’s issued and outstanding warrants as a warrant liability and recording that liability at fair value upon issuance and recording any subsequent changes in fair value as of the end of each period for which earnings are reported. The impact of changes in fair value on earnings may have an adverse effect on EVgo’s balance sheet and statement of operations and/or the market price of the Class A common stock.

If securities or industry analysts cease publishing research or reports about the Company, EVgo’s business, or EVgo’s market, or if they issue negative recommendations regarding EVgo’s securities, the price and trading volume of EVgo’s securities could decline.

The trading market for EVgo’s securities is influenced by the research and reports that industry or securities analysts publish about the Company, EVgo’s business, market and competitors. While securities and industry analysts do currently publish research on the Company, there is no guarantee that they will continue to do so. If securities or industry analysts stop covering the Company or issue negative recommendations regarding the Company’s securities, EVgo’s share price and trading volume may be negatively impacted.

Item 1B. Unresolved Staff Comments.

Not applicable.

​

Item 1C. Cybersecurity Risk Management, Strategy and Governance.

Risk Management and Strategy

The Company maintains a cybersecurity risk management program designed to mitigate cybersecurity risks through a comprehensive framework that integrates cybersecurity into the Company’s overall risk management processes.

Risk Assessment. The Company’s internal cybersecurity team conducts regular assessments designed to identify vulnerabilities within the Company’s systems and processes. These assessments are part of the Company’s ongoing risk management strategy and inform strategic decisions regarding security investments and policy developments. The internal risk assessment process includes periodic reviews of the Company’s charging infrastructure, software applications and operational procedures against best practices and address current and potential threats.

To augment the Company’s internal efforts, the Company engages third parties to conduct independent assessments of the Company’s cybersecurity posture. These external assessments provide an objective review of the Company’s security controls, breach readiness and compliance with industry standards and regulations. The insights gained from these audits inform refinements to the Company’s risk management strategies with respect to cybersecurity-related threats.

Cybersecurity Policies and Procedures. The Company maintains a set of cybersecurity policies and procedures that are regularly reviewed and updated. These policies are crafted in accordance with the National Institute of Standards and Technology (“NIST”) Cybersecurity Framework, which provides a policy foundation for critical infrastructure security. These policies govern the Company’s cybersecurity program, including but not limited to access control, system development life cycle management, change management, and incident response.

Monitoring Controls. In addition to the Company’s cybersecurity policies and procedures, the Company places a significant emphasis on monitoring controls as a critical component of its cybersecurity strategy. These controls are designed to enable the Company to consistently oversee and evaluate the effectiveness of the Company’s cybersecurity measures to help ensure prompt detection of and response to potential threats or anomalies.

The Company maintains a continuous monitoring strategy that utilizes advanced tools and technologies to oversee the Company’s network infrastructure and digital assets. This includes data loss prevention controls, system log reviews and

unusual activities that could indicate a potential security breach. Automated alert systems deployed as part of the Company’s monitoring controls are designed to enable rapid identification and escalation of suspicious activities. These systems are configured to detect a range of cyber threats, from malware infections to unauthorized access attempts.

Cyber Incident Response and Reporting. The Company’s Security Incident Response Policy is designed to enable prompt and effective action in the event of a cybersecurity incident to safeguard the Company’s information technology systems, customer data and overall business operations. The Company is cognizant of the ever-evolving landscape of cybersecurity threats and their potential to materially impact the Company’s operations. To date, the Company does not believe that it has experienced any cybersecurity incidents that have had a material adverse effect on the Company’s business strategy, operations or financial condition. However, the Company recognizes that cybersecurity threats are a significant risk factor for any organization, especially those involved in digital infrastructure. See Part I, Item 1A, “Risk Factors,” for further discussion.

Detection and Analysis. Under the Security Incident Response Policy, all EVgo employees and other personnel are responsible for reporting any known, suspected or possible security events, including those that may have originated with a third-party service provider, to the Company’s Information Security Department, which promptly notifies the Company’s President, who serves as the Company’s Information Security Coordinator. The Information Security Coordinator reviews the initial facts and findings regarding any security events, provides direction to the Information Security Department regarding any additional information that should be obtained, and convenes a meeting of the Company’s Security Incident Response Team (the “SIRT”) to review the matter, including to determine if the event could constitute a security incident.

The SIRT is composed of employees with expertise in various aspects of EVgo’s operations including information security, information technology, DevOps, legal, and EVSE engineering, as well as senior leaders, including EVgo’s President, Chief Financial Officer and Chief Legal Officer.

Materiality Assessment, Mitigation and Reporting. Under the Company’s Security Incident Response Policy, the SIRT, under the leadership of the Information Security Coordinator, is responsible for promptly assessing the materiality of security events, developing the Company’s response to such events and, if a security event is determined to be a material incident, to oversee the Company’s disclosures regarding the incident as required by the rule adopted by the SEC related to cybersecurity disclosures. In determining whether a security event could constitute a security incident, the SIRT considers all facts and known information, including (without limitation) the potential harm to customers, employees and other parties; possible effects on the Company’s operations, financial statements, brand perception, reputation, customer or vendor relationships and competitiveness; the risk of fraud, extortion or intellectual property theft; litigation, regulatory and other legal risk; and other potential impacts. The Chair of the Audit Committee is informed of the SIRT’s review of cybersecurity events and its determinations as to the materiality of such events. The Security Incident Response Policy also includes procedures for the SIRT to coordinate the containment, eradication, mitigation, recovery and remediation related to security events and security incidents and the implementation of procedures and actions designed to prevent additional security events in the future.

The Company also conducts regular cybersecurity training for employees to ensure they are aware of potential cybersecurity threats and understand the role they play in maintaining the Company’s defenses. The Company also monitors evolving regulations and standards to ensure that the Company’s practices align with industry best practices and legal and regulatory obligations.

Governance

Board Oversight of Cybersecurity. The Audit Committee of the Company’s Board of Directors (the “Audit Committee”), acting pursuant to authority delegated by the full Board of Directors, actively oversees the Company’s cybersecurity strategy and risks from cybersecurity threats, as well as the Company’s broader enterprise risk management framework. The Company’s management-level Enterprise Risk Committee meets regularly to review the Company’s risk profile and develop mitigation strategies with respect to those risks. The Audit Committee reviews the enterprise risk matrix prepared by the Enterprise Risk Committee on an annual basis.

Board’s Oversight Role. The Audit Committee reviews and assesses the Company’s risk management program and cybersecurity activities and strategy to help align with the Company’s business objectives and compliance with legal and

regulatory standards. These updates include reviews of new or evolving cybersecurity threats, the Company’s cybersecurity measures, the results of recent third-party security audits, and assessments and oversight of any recent cybersecurity events with certain characteristics that may have occurred. This oversight role includes evaluating the effectiveness of policies and procedures designed to protect Company assets and sensitive customer information from cyber threats. The Chair of the Audit Committee regularly reports on the Audit Committee’s oversight activities related to enterprise risk management and cybersecurity to the full Board of Directors. The Information Security Coordinator promptly notifies the Chair of the Audit Committee of any security events reviewed by the SIRT, the SIRT’s determination of whether a security event is reportable on Form 8-K pursuant to the SEC Cyber Rule and the factors underlying that determination. If the SIRT determines that a cybersecurity incident is likely material and therefore reportable on Form 8-K, a draft of the Form 8-K will be provided to the Audit Committee for review and comment prior to the Company filing the Form 8-K within the deadline specified by the SEC Cyber Rule. The Audit Committee’s active engagement with and oversight of the Company’s cybersecurity program helps foster a culture of security awareness throughout the Company.

Item 2. Properties.

EVgo’s corporate headquarters is located at 11835 West Olympic Boulevard, Suite 900E, Los Angeles, California, 90064. As of February 15, 2024, the Company leased facilities and land throughout the U.S. for additional offices, a testing facility, and a warehouse. The Company believes its existing facilities and equipment are in good operating condition and are suitable for the conduct of its business.

In addition, the Company has entered into agreements with Site Hosts, which allow the Company to operate charging stations on Site Hosts’ properties and which, collectively, EVgo considers to be material to EVgo’s operations. The agreements with the Site Hosts, which are deemed to be operating leases, are located throughout the geographical areas in which EVgo operates and may include one or more provisions to compensate the Site Hosts, such as fixed fees, cost reimbursements, revenue sharing and payments per customer charge. The expenses related to these agreements are recorded in cost of sales for sites that are operational. Expenses for sites that are not operational are charged to general and administrative expenses.

The Company has determined that it operates in one operating and reportable segment and, as such, the leases and agreements with the Site Hosts are attributable to that segment. EVgo believes all the properties that it currently occupies are suitable for their intended uses. EVgo believes that its current facilities are sufficient to conduct EVgo’s operations. However, EVgo continues to evaluate the potential purchase or lease of additional properties.

Item 3. Legal Proceedings.

From time to time, EVgo may be a party to legal proceedings or subject to claims arising in the ordinary course of business. EVgo is not currently a party to any material legal proceedings.

Item 4. Mine Safety Disclosures.

Not applicable.

​

​

PART II

Item 5. Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities.

EVgo’s Class A common stock trades on the Nasdaq under the symbol “EVGO.” Prior to July 1, 2021 and before the completion of the business combination with CRIS, the Class A common stock of CRIS traded on the NYSE under the ticker symbol “CLII.” EVgo’s Public Warrants trade on the Nasdaq under the symbol “EVGOW.” Prior to July 1, 2021 and before the completion of the business combination with CRIS, the Public Warrants of CRIS traded on the NYSE under the ticker symbol “CLII WS.”

As of February 27, 2024, there were 31 holders of record of EVgo’s Class A common stock and six holders of record of EVgo’s warrants. In addition to holders of record of EVgo’s Class A common stock and warrants, EVgo believes there is a substantially greater number of “street name” holders or beneficial holders whose Class A common stock and warrants are held of record by banks, brokers and other financial institutions. There is no public market for EVgo’s Class B common stock, and there is one holder of record of EVgo’s Class B common stock.

EVgo has not paid any cash dividends on EVgo’s Class A common stock to date. The payment of cash dividends is subject to the discretion of EVgo’s Board of Directors and may be affected by various factors, including EVgo’s future earnings, financial condition, capital requirements, share repurchase activity, current and future planned strategic growth initiatives, levels of indebtedness and other considerations EVgo’s Board of Directors deem relevant.

The performance graph has been omitted as permitted under rules applicable to smaller reporting companies.

Item 6. [Reserved]

​

​

Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations.

The following discussion and analysis provides information that management believes is relevant to an assessment and understanding of EVgo’s consolidated results of operations and financial condition. The discussion should be read in conjunction with EVgo’s consolidated financial statements and the related notes thereto as of and for the years ended December 31, 2023 and 2022, included elsewhere in this Annual Report. In addition to historical information, this discussion contains forward-looking statements that involve numerous risks, uncertainties and assumptions that could cause EVgo’s actual results to differ materially from management’s expectations due to a number of factors, including those discussed in the sections entitled “Risk Factors” and “Cautionary Statement Regarding Forward-Looking Statements” in this Annual Report.

​

Overview

EVgo is a leader in EV charging solutions, building and operating the infrastructure and tools needed to expedite the mass adoption of EVs for individual drivers, rideshare and commercial fleets, and businesses. EVgo is one of the nation’s largest public fast charging networks, featuring over 950 fast charging locations across more than 35 states, including stations built through EVgo eXtend, its white label service offering. EVgo is accelerating transportation electrification through partnerships with automakers, fleet and rideshare operators, retail hosts such as grocery stores, shopping centers, and gas stations, policy leaders, and other organizations.

The foundation of the Company’s business is building, owning and operating EV fast charging sites that deliver charging to EVs driven by individuals, commercial drivers, and fleet operators. EVgo’s core revenue stream is from the provision of charging services for EVs of all types on EVgo’s network. In addition, a variety of business-to-business commercial relationships provide EVgo with revenue or cash payments based on commitments to build new infrastructure, provide guaranteed access to charging, and offer marketing, data and software-driven services. EVgo also earns revenue from the sale of regulatory credits generated through sales of electricity and its operation and ownership of its DCFC network. EVgo believes this combination of revenue streams can drive long-term margin expansion and customer retention.

Specifically, charging network revenue is earned through the following streams:

In addition to offering access to its public network, EVgo offers dedicated charging solutions to fleets. Through its fleet product, EVgo develops, builds, and services charging assets for fleets either at their own depot locations

or at off-site charging hubs that EVgo has secured without requiring a fleet to directly incur capital expenditures. EVgo offers a variety of pricing models for dedicated charging solutions, including a mix of volumetric commitments and variable and fixed payments for provision of charging services. Together, EVgo’s dedicated charging solutions and public fleet charging services provide fleets with charging infrastructure options that are robust and flexible as the transition to electrified transportation accelerates.

EVgo generates non-charging network revenue from the following streams:

Recent Developments

Geopolitical and Macroeconomic Environment

During the last several years, the global economy has experienced disruption and sustained volatility due to a number of factors. For example, the conflict between Russia and Ukraine and an escalation of tensions and conflict in Israel and the broader Middle East region have led to disruptions, instability and volatility in global markets and industries and will likely continue to lead to, geopolitical instability, market uncertainty and supply disruptions. Additionally, recent

inflationary pressures have resulted in and may continue to result in increases to the costs of charging equipment and personnel, which could in turn cause capital expenditures and operating costs to rise. Sustained levels of high inflation have likewise caused the U.S. Federal Reserve and other central banks to increase interest rates, which could have the effects of raising the cost of capital and depressing economic growth.

The current economic environment remains uncertain, and the extent to which EVgo’s operating and financial results for future periods will be impacted by the conflicts in Ukraine, Israel and the broader Middle East region, rates of inflation, instability in the financial services sector, supply-chain disruptions, government efforts to reduce inflation and any recession will largely depend on future developments, which are highly uncertain and cannot be reasonably estimated at this time. In addition, continued long lead times of grid equipment such as transformers may impact EVgo’s development cycle.

Government EV Initiatives

In order to encourage the use of EVs, the U.S. federal government and some state and local governments provide incentives to end users and owners of EVs and EV charging stations in the form of rebates, tax credits, low-cost funding and other financial incentives that promote EV adoption and related EV charging infrastructure. EVgo believes the promotion of EVs and the installation of related EV charging infrastructure will continue in part due to the ongoing implementation of the Infrastructure Investment and Jobs Act (the “Bipartisan Infrastructure Law”) and the Inflation Reduction Act of 2022 (the “Inflation Reduction Act”), which included extensions, expansions and revisions of various tax credits relating to EVs and EV charging infrastructure and may provide more flexibility and options in monetizing such credits. In particular, the Inflation Reduction Act (i) expanded and extended tax credits for EV charging infrastructure and new EVs while also imposing new limitations and requirements for such credits, (ii) introduced tax credits for used EVs and commercial EVs and (iii) introduced the concept of transferability for certain tax credits, providing an additional option to monetize such credits.

However, these incentives may expire on a particular date, end when the allocated funding is exhausted, or may be reduced or terminated as a matter of regulatory or legislative policy. For example, the results of the 2024 Presidential and Congressional elections and resulting legislative or regulatory actions, if pursued, could impact the availability or value of these incentives or reduce access to such low-cost funding. Further, the impact of the Inflation Reduction Act and other government EV initiatives, including regulatory requirements and restrictions that may impact the ability of EVgo and its competitors to take advantage of such initiatives, cannot be known with any certainty at this time, and EVgo may not reap any or all of the expected benefits of the Inflation Reduction Act or the Bipartisan Infrastructure Law. For example, federal guidance on Buy America requirements applicable to the National Electric Vehicle Infrastructure (“NEVI”) Program, which was established by the Bipartisan Infrastructure Law, requires domestic assembly and U.S. steel requirements for chargers to qualify for funding under the NEVI program, with higher domestic content percentages required in 2024. These requirements could increase costs and lead to delays in the installation of EV chargers in the U.S. as charging providers and their customers adjust their build-out plans in order to accommodate these added Buy America requirements, which could result in delays in receipt of revenue from customers. Similarly, regulations proposed and guidance issued by the U.S. Department of the Treasury to implement domestic content, assembly and “foreign entity of concern” eligibility requirements to qualify for EV tax credits passed in the Inflation Reduction Act may reduce incentives available to encourage the adoption of EVs, which could negatively affect the EV market and adversely impact EVgo’s business operations and expansion potential.

In addition to NEVI funding, which has been made available to every state department of transportation to administer grant programs to support the deployment of charging infrastructure, a number of states also offer various rebates, grants and tax credits to incentivize both EV and EVSE purchases. Additionally, in many states, utilities offer rebates or other incentive programs, typically called “make-ready” programs, to incent the development of EV charging infrastructure.

Key Components of Results of Operations

Revenue

EVgo’s revenue is generated across various business lines. The majority of EVgo’s revenue is generated from the sale of charging services, which are comprised of retail, commercial and OEM business lines, and its eXtend offering. In addition, EVgo generates ancillary revenue through the sale of data services and consumer retail services. EVgo also offers network services to OEM customers, including memberships and marketing. Finally, as a result of owning and operating the EV charging stations, EVgo earns regulatory credits such as LCFS credits, which are sold to generate additional revenue.

Cost of Sales

Charging Network. Charging network cost of sales consists primarily of energy usage fees, site operating and maintenance expenses, network charges, warranty and repair services, and site lease and related expenses associated with charging stations.

Other. Other cost of sales is primarily related to costs associated with the eXtend business and the sale of data services and other ancillary services.

Depreciation, Net of Capital-Build Amortization. Depreciation, net of capital-build amortization, consists of depreciation related to EVgo’s property and equipment associated with charging equipment and installation and is partially offset by the amortization of EVgo’s capital-build liabilities associated with third-party funding received for charging stations and other programs.

Gross Profit (Loss) and Gross Margin

Gross profit (loss) consists of EVgo’s revenue less its total cost of sales. Gross margin is gross profit (loss) as a percentage of revenue.

Operating Expenses

General and Administrative. General and administrative expenses primarily consist of payroll and related personnel expenses, IT and office services, customer service, office rent expense and professional services. EVgo expects its general and administrative expenses to increase in absolute dollars as it continues to grow its business. EVgo also expects to continue to incur additional expenses related to compliance and reporting obligations pursuant to the rules and regulations of the SEC, general insurance and directors’ and officers’ insurance, investor relations and other professional services.

Depreciation, Amortization and Accretion. Depreciation, amortization and accretion consists of depreciation related to EVgo’s property, equipment and software not associated with charging equipment and, therefore, not included in the depreciation, net of capital-build amortization expenses recorded in cost of sales. This also includes amortization of EVgo’s intangible assets and accretion related to EVgo’s asset retirement obligations.

Operating Profit (Loss) and Operating Margin

Operating profit (loss) consists of EVgo’s gross profit (loss) less total operating expenses. Operating margin is operating profit (loss) as a percentage of revenue.

Interest Income

Interest income consists primarily of interest earned on cash, cash equivalents and debt securities.

Other (Expense) Income, Net

Other (expense) income, net, consists primarily of unrealized gains and losses on marketable securities.

Change in Fair Values of Warrant and Earnout Liabilities

The change in the fair values of the warrant and earnout liabilities reflects the mark-to-market adjustments associated with warrants to purchase shares of the Company’s common stock and earnout liabilities for each reporting period.

Income Taxes

EVgo’s provision for income taxes consists primarily of income taxes related to federal and state jurisdictions where business is conducted related to the Company’s ownership in EVgo OpCo. For the years ended December 31, 2023 and 2022, EVgo’s provision for income taxes and effective tax rate were deemed to be de minimis. As of December 31, 2023 and 2022, EVgo maintained a full valuation allowance on EVgo’s net deferred tax assets. There were no unrecognized tax benefits for uncertain tax positions, nor any significant amounts accrued for interest and penalties as of December 31, 2023 and 2022.

Net Earnings (Loss) Attributable to Redeemable Noncontrolling Interest

Net earnings (loss) attributable to redeemable noncontrolling interest represents the share of net earnings or loss that is attributable to the holder of EVgo’s Class B common stock.

Key Performance Indicators

EVgo management uses several performance metrics to manage the business and evaluate financial and operating performance:

Network Throughput on the EVgo Network

Network throughput represents the total amount of GWh consumed by EVs using chargers and charging stations that EVgo has operational on its network (excluding eXtend chargers and charging stations) (the “EVgo Network”). EVgo typically monitors GWh sales by three components: business line, customer and customer class. EVgo believes monitoring of component trends and contributions is the appropriate way to monitor and measure business-related health.

Number of DC Stalls on the EVgo Network

Number of DC stalls represents the total number of DC stalls (energized, inspected and commissioned) on the EVgo Network (“DC Stalls”). One stall can charge one vehicle at a time. There are certain configurations of EVgo sites where one DC charger is capable of charging only one vehicle at a time; all chargers at such a site are counted as one stall per one charger. There are certain configurations of EVgo sites where one DC charger is capable of charging two vehicles simultaneously; all chargers at such a site are counted as two stalls per one charger.

The following table presents network throughput and the number of DC stalls on the EVgo Network:

Factors Affecting EVgo’s Operating Results

EVgo believes its performance and future success depend on a number of factors, including those discussed below and in Part I, Item 1A, “Risk Factors.”

EV Sales

EVgo’s revenue growth is directly tied to the adoption and continued acceptance and usage of passenger and commercial EVs, which it believes drives the demand for electricity, charging infrastructure and charging services. The market for EVs is still rapidly evolving and, although demand for EVs has grown in recent years, there is no guarantee of such future demand. Additionally, as demand increases, the supply must keep pace for adoption to continue to accelerate at a rapid pace. Factors impacting the adoption of EVs include perceptions about EV features, quality, safety, performance and cost; perceptions about the limited range over which EVs may be driven on a single battery charge; availability of services for EVs; consumers’ perception about the convenience, speed, reliability and cost of EV charging; volatility in the price of gasoline and diesel; EV supply chain shortages and disruptions including, but not limited to, availability of certain components (e.g., semiconductors and critical raw materials necessary for the production of EVs and EV batteries), the ability of EV OEMs to ramp-up EV production and/or allocate sufficient quantities of EV models to the U.S. market; domestic content requirements or other policy constraints; availability of batteries and battery materials; availability, cost and desirability of other alternative fuel vehicles, including plug-in hybrid EVs and high fuel-economy gasoline and diesel-powered vehicles; increases in fuel efficiency; regulations applicable to vehicle emissions and fuel economy; and availability of federal and state credits for EV purchases. In addition, macroeconomic factors could impact demand for EVs, particularly since the sales price of EVs can be more expensive than traditional gasoline-powered vehicles. If the market for EVs does not develop as expected or if there is any slowdown or delay in overall adoption of EVs, EVgo’s operating results may be adversely affected.

Electrification of Fleets

EVgo faces competition in the emerging fleet electrification segment, including from certain fleet customers who may opt to install and own charging equipment on their property; however, EVgo believes its unique set of offerings to fleets and its existing charging network position EVgo advantageously to win business from fleets. Fleet owners are generally more sensitive to the total cost of ownership of a vehicle than private-vehicle owners. As such, electrification of vehicle fleets may occur more slowly or more rapidly than management forecasts based on the cost to purchase, operate and maintain EVs and the general availability of such vehicles relative to those of internal combustion engine vehicles. The ability of EVgo and its competitors to offer competitive charging services and value-added ancillary services may impact the pace at which fleets electrify and may impact EVgo’s ability to capture market share in fleets. Additionally, federal, state and local government support and regulations directed at fleets (or lack thereof) may accelerate or delay fleet electrification and increase or reduce EVgo’s business opportunity.

Competition

The EV charging industry is increasingly competitive. The principal competitive factors in the industry include charger count, locations, accessibility and reliability; charger connectivity to EVs and ability to charge widely adopted standards; speed of charging relative to expected vehicle dwell times at a location; DCFC network reliability, scale and local density; software-enabled service offerings and overall customer experience; operator brand, track record and reputation; access to equipment vendors and service providers; policy incentives; and pricing. Existing competitors may expand their product offerings and sales strategies, new competitors may enter the market and certain fleet customers may

choose to install and operate their own charging infrastructure. If EVgo’s market share decreases due to increased competition, its revenue and ability to generate profits in the future may be impacted.

Government Mandates, Incentives and Programs

The U.S. federal government and some state and local governments provide incentives to end users and owners of EVs and EV charging stations in the form of rebates, tax credits, low-cost funding and other financial incentives, such as payments for regulatory credits. The EV market relies on these governmental rebates, tax credits and other financial incentives to significantly lower the effective price of EVs and EV charging stations and to otherwise financially support these industries. However, these incentives may expire on a particular date, end when the allocated funding is exhausted, or may be reduced or terminated as a matter of regulatory or legislative policy. For example, the results of the 2024 Presidential and Congressional elections and resulting legislative or regulatory actions, if pursued, could impact the availability or value of these incentives or reduce access to such low-cost funding. Further, EVgo has historically claimed federal tax credits under Section 30C of the Code. The Inflation Reduction Act revised the eligibility criteria for these credits, and there can be no assurance that the EV charging stations placed into service by EVgo will meet the revised requirements, and compliance with such requirements could increase EVgo’s labor and other costs. Any reduction in rebates, tax credits or other financial incentives available to EVs or EV charging stations could negatively affect the EV market and adversely impact EVgo’s business operations and expansion potential. In addition, there is no assurance that EVgo will have the necessary tax attributes to utilize any such credits that are available and may not be able to monetize such credits on favorable terms. Further, certain features of EVgo OpCo’s ownership may limit the available tax credit that can be monetized or utilized. See Part I, Item 1A, “Risk Factors — Risks Related to the EV Market — The EV market currently benefits from the availability of rebates, tax credits and other financial incentives from governments, utilities and others to offset the purchase or operating cost of EVs and EV charging stations. The reduction, modification or elimination of such benefits could adversely affect EVgo’s financial results.” for further discussion.

Technology Risks

EVgo relies on numerous internally developed and externally sourced hardware and software technologies to operate its network and generate earnings. EVgo engages a variety of third-party vendors for non-proprietary hardware and software components and software-as-a-service elements. The ability of EVgo to continue to integrate its technology stack with technological advances in the wider EV ecosystem including EV model characteristics, charging standards, charging hardware, software and battery chemistries and value-added customer services will determine EVgo’s sustained competitiveness in offering charging services. There is a risk that some or all of the components of the EV technology ecosystem become obsolete and that EVgo will be required to make significant investments to continue to effectively operate its business. For example, a majority of the largest OEMs have announced plans to adopt the NACS standard in their future EVs. SAE International, a standards-developing organization for automotive engineering professionals, is currently working on an initiative to adapt Tesla’s specifications for NACS into the SAE J3400 industry standard. EVgo has announced that it will be adding NACS connectors to its fast-charging network in 2025; however, integrating NACS connectors in future charger installations and on certain existing chargers will require significant investment and management attention.

EVgo’s management believes EVgo’s business model is well-positioned to enable EVgo to remain technology-, vendor- and OEM-agnostic over time and allow the business to remain competitive regardless of long-term technological shifts in EVs, batteries or modes of charging.

Sales of Regulatory Credits

EVgo derives revenue from selling regulatory credits earned for participating in LCFS programs, or other similar carbon or emissions trading schemes, in various jurisdictions in the U.S. EVgo currently sells these credits at market prices. These credits are exposed to various market and supply and demand dynamics which can drive price volatility and which are difficult to predict. Price fluctuations in credits may have a material effect on future results of operations. The availability of such credits depends on continued governmental support for these programs. If these programs are modified, reduced or eliminated, EVgo’s ability to generate this revenue in the future would be adversely impacted. In addition to

current programs, EVgo is currently monitoring additional proposals related to potential LCFS programs in varying stages of discussions, including in New York, along with potential changes to the Renewable Fuels Standard.

Results of Operations

Year Ended December 31, 2023 Compared with Year Ended December 31, 2022

The table below presents EVgo’s results of operations for the years ended December 31, 2023 and 2022: